Form 10-Q
Table of Contents

 

 

UNITED STATES

SECURITIES AND EXCHANGE COMMISSION

WASHINGTON, D.C. 20549

 

 

FORM 10-Q

(Mark One)

 

  x QUARTERLY REPORT PURSUANT TO SECTION 13 OR 15(d) OF THE SECURITIES EXCHANGE ACT OF 1934

For the Quarterly Period Ended June 30, 2011

or

 

  ¨ TRANSITION REPORT PURSUANT TO SECTION 13 OR 15(d) OF THE SECURITIES EXCHANGE ACT OF 1934

Commission file number 1-12291

LOGO

THE AES CORPORATION

(Exact name of registrant as specified in its charter)

 

Delaware   54 1163725

(State or other jurisdiction of

incorporation or organization)

 

  (I.R.S. Employer Identification No.)
4300 Wilson Boulevard Arlington, Virginia   22203
(Address of principal executive offices)   (Zip Code)

(703) 522-1315

Registrant’s telephone number, including area code:

 

 

Indicate by check mark whether the registrant (1) has filed all reports required to be filed by Section 13 or 15(d) of the Securities Exchange Act of 1934 during the preceding 12 months (or for such shorter period that the registrant was required to file such reports), and (2) has been subject to such filing requirements for the past 90 days.  Yes  x    No  ¨

Indicate by check mark whether the registrant has submitted electronically and posted on its corporate Web site, if any, every Interactive Data File required to be submitted and posted pursuant to Rule 405 of Regulation S-T (§232.405 of this chapter) during the preceding 12 months (or for such shorter period that the registrant was required to submit and post such files).  Yes  x    No  ¨

Indicate by check mark whether the registrant is a large accelerated filer, an accelerated filer, a non-accelerated filer, or a smaller reporting company. See the definitions of “large accelerated filer”, “accelerated filer”, and “smaller reporting company” in Rule 12b-2 of the Exchange Act. (Check one):

 

Large accelerated filer  x    Accelerated filer  ¨    Non-accelerated filer  ¨    Smaller reporting company  ¨
      (Do not check if a smaller reporting company)   

Indicate by check mark whether the registrant is a shell company (as defined in Rule 12b-2 of the Exchange Act).  Yes  ¨    No  x

 

 

The number of shares outstanding of Registrant’s Common Stock, par value $0.01 per share, on July 29, 2011 was 782,403,030.

 

 

 


Table of Contents

THE AES CORPORATION

FORM 10-Q

FOR THE QUARTERLY PERIOD ENDED JUNE 30, 2011

TABLE OF CONTENTS

 

PART I: FINANCIAL INFORMATION

     1   

ITEM 1.

  FINANCIAL STATEMENTS      1   
  Condensed Consolidated Statements of Operations      1   
  Condensed Consolidated Balance Sheets      2   
  Condensed Consolidated Statements of Cash Flows      3   
  Condensed Consolidated Statements of Changes in Equity      4   
  Notes to Condensed Consolidated Financial Statements      5   

ITEM 2.

  MANAGEMENT’S DISCUSSION AND ANALYSIS OF FINANCIAL CONDITION AND RESULTS OF OPERATIONS      45   

ITEM 3.

 

QUANTITATIVE AND QUALITATIVE DISCLOSURES ABOUT MARKET RISK

     88   

ITEM 4.

 

CONTROLS AND PROCEDURES

     90   

PART II: OTHER INFORMATION

     91   

ITEM 1.

 

LEGAL PROCEEDINGS

     91   

ITEM 1A.

 

RISK FACTORS

     100   

ITEM 2.

 

UNREGISTERED SALES OF EQUITY SECURITIES AND USE OF PROCEEDS

     100   

ITEM 3.

 

DEFAULTS UPON SENIOR SECURITIES

     100   

ITEM 4.

 

REMOVED AND RESERVED

     100   

ITEM 5.

 

OTHER INFORMATION

     100   

ITEM 6.

 

EXHIBITS

     101   


Table of Contents

PART I: FINANCIAL INFORMATION

ITEM 1. FINANCIAL STATEMENTS

THE AES CORPORATION

Condensed Consolidated Statements of Operations

(Unaudited)

 

    Three Months Ended
June 30,
    Six Months Ended
June 30,
 
    2011     2010     2011     2010  
    (in millions, except per share amounts)  

Revenue:

       

Regulated

  $       2,483     $       2,213     $       4,896     $       4,454  

Non-Regulated

    2,061       1,710       3,912       3,389  
 

 

 

   

 

 

   

 

 

   

 

 

 

Total revenue

    4,544       3,923       8,808       7,843  
 

 

 

   

 

 

   

 

 

   

 

 

 

Cost of Sales:

       

Regulated

    (1,905     (1,641     (3,728     (3,307

Non-Regulated

    (1,620     (1,280     (3,045     (2,573
 

 

 

   

 

 

   

 

 

   

 

 

 

Total cost of sales

    (3,525     (2,921     (6,773     (5,880
 

 

 

   

 

 

   

 

 

   

 

 

 

Gross margin

    1,019       1,002       2,035       1,963  
 

 

 

   

 

 

   

 

 

   

 

 

 

General and administrative expenses

    (97     (101     (192     (181

Interest expense

    (396     (389     (747     (770

Interest income

    97       101       192       209  

Other expense

    (38     (48     (55     (60

Other income

    34       68       50       77  

Gain on sale of investments

    1       -        7       -   

Asset impairment expense

    (33     (1     (33     (1

Foreign currency transaction gains (losses) on net monetary position

    38       (71     71       (122

Other non-operating expense

    -        (5     -        (5
 

 

 

   

 

 

   

 

 

   

 

 

 

INCOME FROM CONTINUING OPERATIONS BEFORE TAXES AND EQUITY IN EARNINGS OF AFFILIATES

    625       556       1,328       1,110  

Income tax expense

    (178     (261     (396     (447

Net equity in earnings of affiliates

    (3     134       7       147  
 

 

 

   

 

 

   

 

 

   

 

 

 

INCOME FROM CONTINUING OPERATIONS

    444       429       939       810  

Income (loss) from operations of discontinued businesses, net of income tax (benefit) expense of $(7), $(6), $(13) and $5, respectively

    (17     9       (29     43  

Gain from disposal of discontinued businesses, net of income tax (benefit) expense of $0, $0, $0 and $0, respectively

    -        (9     -        (22
 

 

 

   

 

 

   

 

 

   

 

 

 

NET INCOME

    427       429       910       831  

Noncontrolling interests:

       

Less: Income from continuing operations attributable to noncontrolling interests

    (253     (277     (512     (488

Less: Income from discontinued operations attributable to noncontrolling interests

    -        (8     -        (12
 

 

 

   

 

 

   

 

 

   

 

 

 

Total net income attributable to noncontrolling interests

    (253     (285     (512     (500
 

 

 

   

 

 

   

 

 

   

 

 

 

NET INCOME ATTRIBUTABLE TO THE AES CORPORATION

  $ 174     $ 144     $ 398     $ 331  
 

 

 

   

 

 

   

 

 

   

 

 

 

BASIC EARNINGS PER SHARE:

       

Income from continuing operations attributable to The AES Corporation common stockholders, net of tax

  $ 0.24     $ 0.19     $ 0.55     $ 0.43  

Discontinued operations attributable to The AES Corporation common stockholders, net of tax

    (0.02     (0.01     (0.04     0.01  
 

 

 

   

 

 

   

 

 

   

 

 

 

NET INCOME ATTRIBUTABLE TO THE AES CORPORATION

       

COMMON STOCKHOLDERS

  $ 0.22     $ 0.18     $ 0.51     $ 0.44  
 

 

 

   

 

 

   

 

 

   

 

 

 

DILUTED EARNINGS PER SHARE:

       

Income from continuing operations attributable to The AES Corporation common stockholders, net of tax

  $ 0.24     $ 0.19     $ 0.54     $ 0.43  

Discontinued operations attributable to The AES Corporation common stockholders, net of tax

    (0.02     (0.01     (0.04     0.01  
 

 

 

   

 

 

   

 

 

   

 

 

 

NET INCOME ATTRIBUTABLE TO THE AES CORPORATION

       

COMMON STOCKHOLDERS

  $ 0.22     $ 0.18     $ 0.50     $ 0.44  
 

 

 

   

 

 

   

 

 

   

 

 

 

AMOUNTS ATTRIBUTABLE TO THE AES CORPORATION

       

COMMON STOCKHOLDERS:

       

Income from continuing operations, net of tax

  $ 191     $ 152     $ 427     $ 322  

Discontinued operations, net of tax

    (17     (8     (29     9  
 

 

 

   

 

 

   

 

 

   

 

 

 

Net income

  $ 174     $ 144     $ 398     $ 331  
 

 

 

   

 

 

   

 

 

   

 

 

 

See Notes to Condensed Consolidated Financial Statements

 

1


Table of Contents

THE AES CORPORATION

Condensed Consolidated Balance Sheets

 

    June 30,
2011
    December 31,
2010
 
    (in millions, except
share and per share data)
 
    (unaudited)        

ASSETS

   

CURRENT ASSETS

   

Cash and cash equivalents

  $ 3,624     $ 2,552  

Restricted cash

    530       502  

Short-term investments

    1,231       1,730  

Accounts receivable, net of allowance for doubtful accounts of $348 and $307, respectively

    2,614       2,316  

Inventory

    654       562  

Receivable from affiliates

    25       27  

Deferred income taxes — current

    298       306  

Prepaid expenses

    180       225  

Other current assets

    855       1,056  

Current assets of discontinued and held for sale businesses

    162       170  
 

 

 

   

 

 

 

Total current assets

    10,173       9,446  
 

 

 

   

 

 

 

NONCURRENT ASSETS

   

Property, Plant and Equipment:

   

Land

    1,184       1,126  

Electric generation, distribution assets and other

    31,265       28,172  

Accumulated depreciation

    (9,727     (9,145

Construction in progress

    2,825       4,459  
 

 

 

   

 

 

 

Property, plant and equipment, net

    25,547       24,612  
 

 

 

   

 

 

 

Other Assets:

   

Investments in and advances to affiliates

    1,542       1,320  

Debt service reserves and other deposits

    797       653  

Goodwill

    1,267       1,271  

Other intangible assets, net of accumulated amortization of $172 and $157, respectively

    527       511  

Deferred income taxes — noncurrent

    661       646  

Other

    2,057       1,964  

Noncurrent assets of discontinued and held for sale businesses

    64       88  
 

 

 

   

 

 

 

Total other assets

    6,915       6,453  
 

 

 

   

 

 

 

TOTAL ASSETS

  $ 42,635     $ 40,511  
 

 

 

   

 

 

 

LIABILITIES AND EQUITY

   

CURRENT LIABILITIES

   

Accounts payable

  $ 1,892     $ 2,053  

Accrued interest

    286       257  

Accrued and other liabilities

    2,452       2,662  

Non-recourse debt — current, including $1,203 and $1,150, respectively, related to variable interest entities

    2,320       2,567  

Recourse debt — current

    11       463  

Current liabilities of discontinued and held for sale businesses

    232       63  
 

 

 

   

 

 

 

Total current liabilities

    7,193       8,065  
 

 

 

   

 

 

 

LONG-TERM LIABILITIES

   

Non-recourse debt — noncurrent, including $2,245 and $2,199, respectively, related to variable interest entities

    12,922       12,372  

Recourse debt — noncurrent

    6,182       4,149  

Deferred income taxes — noncurrent

    891       895  

Pension and other post-retirement liabilities

    1,549       1,512  

Other long-term liabilities

    2,938       2,814  

Long-term liabilities of discontinued and held for sale businesses

    63       231  
 

 

 

   

 

 

 

Total long-term liabilities

    24,545       21,973  
 

 

 

   

 

 

 

Contingencies and Commitments (see Note 9)

   

Cumulative preferred stock of subsidiary

    60       60  

EQUITY

   

THE AES CORPORATION STOCKHOLDERS’ EQUITY

   

Common stock ($0.01 par value, 1,200,000,000 shares authorized; 806,836,014 issued and 782,273,322 outstanding at June 30, 2011 and 804,894,313 issued and 787,607,240 outstanding at December 31, 2010

    8       8  

Additional paid-in capital

    8,471       8,444  

Retained earnings

    1,018       620  

Accumulated other comprehensive loss

    (2,278     (2,383

Treasury stock, at cost (24,562,692 shares at June 30, 2011 and 17,287,073 shares at December 31, 2010, respectively)

    (308     (216
 

 

 

   

 

 

 

Total The AES Corporation stockholders’ equity

    6,911       6,473  

NONCONTROLLING INTERESTS

    3,926       3,940  
 

 

 

   

 

 

 

Total equity

    10,837       10,413  
 

 

 

   

 

 

 

TOTAL LIABILITIES AND EQUITY

  $ 42,635     $ 40,511  
 

 

 

   

 

 

 

See Notes to Condensed Consolidated Financial Statements

 

2


Table of Contents

THE AES CORPORATION

Condensed Consolidated Statements of Cash Flows

(Unaudited)

 

     Six Months Ended
June 30,
 
     2011     2010  
     (in millions)  

OPERATING ACTIVITIES:

    

Net income

   $ 910     $ 831  

Adjustments to net income:

    

Depreciation and amortization

     622       584  

Loss from sale of investments and impairment expense

     37       18  

Loss on disposal and impairment write-down — discontinued operations

     -        18  

Provision for deferred taxes

     28       117  

Contingencies

     46       72  

Loss on the extinguishment of debt

     15       9  

Undistributed gain from sale of equity method investment

     -        (115

Other

     (89     (42

Changes in operating assets and liabilities:

    

Increase in accounts receivable

     (182     (69

Increase in inventory

     (88     (1

Decrease in prepaid expenses and other current assets

     152       169  

Increase in other assets

     (43     (51

Decrease in accounts payable and accrued liabilities

     (254     (91

Decrease in income taxes and other income tax payables, net

     (152     (90

Increase in other liabilities

     178       56  
  

 

 

   

 

 

 

Net cash provided by operating activities

     1,180       1,415  
  

 

 

   

 

 

 

INVESTING ACTIVITIES:

    

Capital expenditures

     (1,019     (1,002

Acquisitions — net of cash acquired

     (157     (100

Proceeds from the sale of businesses

     8       198  

Proceeds from the sale of assets

     22       2  

Sale of short-term investments

     3,065       3,139  

Purchase of short-term investments

     (2,493     (3,255

Increase in restricted cash

     (16     (74

Increase in debt service reserves and other assets

     (92     (9

Affiliate advances and equity investments

     (60     (27

Proceeds from loan repayments

     -        132  

Other investing

     (15     41  
  

 

 

   

 

 

 

Net cash used in investing activities

     (757     (955
  

 

 

   

 

 

 

FINANCING ACTIVITIES:

    

Issuance of common stock

     -        1,569  

Borrowings under the revolving credit facilities, net

     125       88  

Issuance of recourse debt

     2,050       -   

Issuance of non-recourse debt

     574       1,343  

Repayments of recourse debt

     (471     (406

Repayments of non-recourse debt

     (768     (1,297

Payments for financing fees

     (74     (29

Distributions to noncontrolling interests

     (714     (542

Financed capital expenditures

     (6     (17

Purchase of treasury stock

     (98     -   

Other financing

     2       (17
  

 

 

   

 

 

 

Net cash provided by financing activities

     620       692  

Effect of exchange rate changes on cash

     29       (44
  

 

 

   

 

 

 

Total increase in cash and cash equivalents

     1,072       1,108  

Cash and cash equivalents, beginning

     2,552       1,780  
  

 

 

   

 

 

 

Cash and cash equivalents, ending

   $ 3,624     $ 2,888  
  

 

 

   

 

 

 

SUPPLEMENTAL DISCLOSURES:

    

Cash payments for interest, net of amounts capitalized

   $ 734     $ 764  

Cash payments for income taxes, net of refunds

   $ 506     $ 429  

See Notes to Condensed Consolidated Financial Statements

 

3


Table of Contents

THE AES CORPORATION

Condensed Consolidated Statements of Changes in Equity

(Unaudited)

 

    THE AES CORPORATION STOCKHOLDERS     Noncontrolling
Interests
    Consolidated
Comprehensive
Income
 
    Common
Stock
    Treasury
Stock
    Additional
Paid-In
Capital
    Retained
Earnings
    Accumulated
Other
Comprehensive
Loss
     
    (in millions)  

Balance at January 1, 2011

  $ 8     $ (216   $ 8,444     $ 620     $ (2,383)      $ 3,940    

Net income

    -        -        -        398       -        512     $         910  

Change in fair value of available-for-sale securities, net of income tax

    -        -        -        -        (2)        -        (2

Foreign currency translation adjustment, net of income tax

    -        -        -        -        118       144       262  

Change in unfunded pensions obligation, net of income tax

    -        -        -        -        2       5       7  

Change in derivative fair value, including a reclassification to earnings, net of income tax

    -        -        -        -        (13)        3       (10
             

 

 

 

Other comprehensive income

                257  
             

 

 

 

Total comprehensive income

              $ 1,167  
             

 

 

 

Capital contributions from noncontrolling interests

    -        -        -        -        -        3    

Distributions to noncontrolling interests

    -        -        -        -        -        (679  

Disposition of businesses

    -        -        -        -        -        (2  

Acquisition of treasury stock

    -        (98     -        -        -        -     

Issuance of common stock under benefit plans and exercise of stock options and warrants, net of income tax

    -        6       13       -        -        -     

Stock compensation

    -        -        14       -        -        -     
 

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

Balance at June 30, 2011

  $         8     $ (308   $         8,471     $         1,018     $ (2,278   $         3,926    
 

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   
    THE AES CORPORATION STOCKHOLDERS              
    Common
Stock
    Treasury
Stock
    Additional
Paid-In
Capital
    Retained
Earnings
    Accumulated
Other
Comprehensive
Loss
    Noncontrolling
Interests
    Consolidated
Comprehensive
Income
 
             
             
             
    (in millions)  

Balance at January 1, 2010

  $ 7     $ (126   $ 6,868     $ 650     $ (2,724   $ 4,205    

Net income

    -        -        -        331       -        500     $ 831  

Change in fair value of available-for-sale securities, net of income tax

    -        -        -        -        (6     -        (6

Foreign currency translation adjustment, net of income tax

    -        -        -        -        302       (68     234  

Change in unfunded pensions obligation, net of income tax

    -        -        -        -        2       3       5  

Change in derivative fair value, including a reclassification to earnings, net of income tax

    -        -        -        -        (138     (31     (169
             

 

 

 

Other comprehensive income

                64  
             

 

 

 

Total comprehensive income

              $ 895  
             

 

 

 

Cumulative effect of consolidation of entities under variable interest entity accounting guidance

    -        -        -        (47     (38     15    

Cumulative effect of deconsolidation of entities under variable interest entity accounting guidance

    -        -        -        1       -        -     

Capital contributions from noncontrolling interests

    -        -        -        -        -        3    

Distributions to noncontrolling interests

    -        -        -        -        -        (646  

Disposition of businesses

    -        -        -        -        -        (14  

Issuance of common stock

    1       -        1,566       -        -        -     

Issuance of common stock under benefit plans and exercise of stock options and warrants, net of income tax

    -        8       9       -        -        -     

Stock compensation

    -        -        14       -        -        -     

Changes in the carrying amount of redeemable stock of subsidiaries

    -        -        -        7       -        -     
 

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

Balance at June 30, 2010

  $ 8     $ (118   $ 8,457     $ 942     $ (2,602   $ 3,967    
 

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

 

 

   

See Notes to Condensed Consolidated Financial Statements

 

4


Table of Contents

THE AES CORPORATION

Notes to Condensed Consolidated Financial Statements

For the Three and Six Months Ended June 30, 2011 and 2010

1. FINANCIAL STATEMENT PRESENTATION

The prior period condensed consolidated financial statements in this Quarterly Report on Form 10-Q (“Form 10-Q”) have been reclassified to reflect the businesses held for sale and discontinued operations as discussed in Note 15 — Discontinued Operations and Held for Sale Businesses.

On June 1, 2011, The AES Corporation filed a Current Report on Form 8-K (“June 2011 Form 8-K”) to recast previously filed financial statements included in the Company’s Form 10-K for the year ended December 31, 2010 (“2010 Form 10-K”) to reclassify certain businesses held for sale as discussed in Note 15 —Discontinued Operations and Held for Sale Businesses. The revisions to the 2010 Form 10-K were limited to the Company’s Business Overview, Selected Financial Data, Management’s Discussion and Analysis of Financial Condition and Results of Operations and the Consolidated Financial Statements and Notes contained in Items 1, 6, 7 and 8, respectively. All other information in the 2010 Form 10-K remains unchanged.

Consolidation

In this Quarterly Report the terms “AES”, “the Company”, “us” or “we” refer to the consolidated entity including its subsidiaries and affiliates. The terms “The AES Corporation”, “the Parent” or “the Parent Company” refer only to the publicly-held holding company, The AES Corporation, excluding its subsidiaries and affiliates. Furthermore, variable interest entities (“VIEs”) in which the Company has a variable interest have been consolidated where the Company is the primary beneficiary. Investments in which the Company has the ability to exercise significant influence, but not control, are accounted for using the equity method of accounting. All intercompany transactions and balances have been eliminated in consolidation.

AES Thames, LLC (“Thames”), a 208 MW coal–fired plant in Connecticut, filed petitions for bankruptcy protection under Chapter 11 in the U.S. Bankruptcy Court on February 1, 2011. Effective that date, the Company lost control of the business and is no longer able to exercise significant influence over its operating and financial policies. In accordance with the accounting guidance on consolidations, Thames was deconsolidated in February 2011 and is now accounted for as a cost method investment. Thames had total assets and total liabilities of $158 million and $170 million, respectively, on February 1, 2011. The deconsolidation resulted in a gain of $12 million, which was deferred pending the completion of the bankruptcy proceedings.

Interim Financial Presentation

The accompanying unaudited condensed consolidated financial statements and footnotes have been prepared in accordance with generally accepted accounting principles in the United States of America (“U.S. GAAP”), as contained in the Financial Accounting Standards Board (“FASB”) Accounting Standards Codification, for interim financial information and Article 10 of Regulation S-X issued by the U.S. Securities and Exchange Commission (“SEC”). Accordingly, they do not include all the information and footnotes required by U.S. GAAP for annual fiscal reporting periods. In the opinion of management, the interim financial information includes all adjustments of a normal recurring nature necessary for a fair presentation of the results of operations, financial position, changes in equity and cash flows. The results of operations for the three and six months ended June 30, 2011 are not necessarily indicative of results that may be expected for the year ending December 31, 2011. The accompanying condensed consolidated financial statements are unaudited and should be read in conjunction with the 2010 audited consolidated financial statements and notes thereto, which are included in the June 2011 Form 8-K.

 

5


Table of Contents

Change in Estimate

On January 1, 2011, the Company changed its estimates related to depreciation on property, plant and equipment at its Brazilian concessionary utility and generation businesses. Based on recent information received from regulators, the depreciation rates and salvage values for its concession assets were adjusted on a prospective basis to reflect a remuneration basis, which equates to the reimbursement expected by the Company at the end of the respective concession periods. For the three months ended June 30, 2011, the impact to the condensed consolidated statement of operations was an increase in depreciation expense of $18 million and a decrease in net income attributable to The AES Corporation of $5 million, or $0.01 per share. For the six months ended June 30, 2011, the impact to the condensed consolidated statement of operations was an increase in depreciation expense of $35 million and a decrease in net income attributable to The AES Corporation of $9 million, or $0.01 per share.

New Accounting Policies Adopted

Accounting Standards Update (“ASU”) No. 2009-13, Revenue Recognition (Topic 605), “Multiple-Deliverable Revenue Arrangements”

In October 2009, the FASB issued ASU No. 2009-13, which amended the accounting guidance related to revenue recognition. The amended guidance provides primarily two changes to the prior guidance for multiple-element revenue arrangements. The first eliminated the requirement that there be “objective and reliable evidence” of fair value for any undelivered items in order for a delivered item to be treated as a separate unit of accounting. The second required that the consideration from multiple-element revenue arrangements be allocated to all the deliverables based on their relative selling price at the inception of the arrangement. AES adopted the standard on January 1, 2011. AES elected prospective adoption and applied the revised guidance to all revenue arrangements entered into or materially modified after the date of adoption. The adoption of ASU No. 2009-13 did not have a material impact on the financial position and results of operations of AES and is not expected to have a material impact in future periods.

ASU No. 2010-28, Intangibles — Goodwill and Other (Topic 350), “When to Perform Step 2 of the Goodwill Impairment Test for Reporting Units with Zero or Negative Carrying Amounts”

In December 2010, the FASB issued ASU No. 2010-28, which amended the accounting guidance related to goodwill. The amendment modified Step One of the goodwill impairment test for reporting units with zero or negative carrying amounts. For those reporting units, an entity is required to perform Step Two of the goodwill impairment test if it is more likely than not that a goodwill impairment exists, eliminating an entity’s ability to assert that a reporting unit is not required to perform Step Two because the carrying amount of the reporting unit is zero or negative, despite the existence of qualitative factors that indicate the goodwill is more likely than not impaired. In determining whether it is more likely than not that a goodwill impairment exists, an entity should consider whether there are any adverse qualitative factors indicating that an impairment may exist. The Company adopted ASU No. 2010-28 on January 1, 2011. The adoption did not have any impact on the Company as none of its reporting units with goodwill has a zero or negative carrying amount.

Accounting Pronouncements Issued But Not Yet Effective

As of June 30, 2011, the following accounting standards have been issued, but are not yet effective for, and have not been adopted by AES.

ASU No. 2011-2, Receivables (Topic 310), “A Creditor’s Determination of Whether a Restructuring Is a Troubled Debt Restructuring”

In April 2011, the FASB issued ASU No. 2011-2, which provides additional guidance and clarification to help creditors determine whether a creditor has granted a concession and whether a debtor is experiencing financial difficulties for purposes of determining whether a restructuring constitutes a troubled debt restructuring.

 

6


Table of Contents

ASU No. 2011-2 is effective for the first interim or annual period beginning on or after June 15, 2011, or July 1, 2011 for AES. The adoption is not expected to have a material impact on the Company’s financial position, results of operations or cash flows.

ASU No. 2011-4, Fair Value Measurements (Topic 820), “Amendments to Achieve Common Fair Value Measurement and Disclosure Requirements in U.S. GAAP and IFRS”

In May 2011, the FASB issued ASU No. 2011-4, which among other requirements, prohibits the use of the block discount factor for all fair value level hierarchies; permits an entity to measure the fair value of its financial instruments on a net basis when the related market risks are managed on a net basis; states the highest and best use concept is no longer relevant in the measurement of financial assets and liabilities; clarifies that a reporting entity should disclose quantitative information about the unobservable inputs used in Level 3 measurements and that the application of premiums and discounts is related to the unit of account for the asset or liability being measured at fair value; and requires expanded disclosures to describe the valuation process used for Level 3 measurements and the sensitivity of Level 3 measurements to changes in unobservable inputs. In addition, entities are required to disclose the hierarchy level for items which are not measured at fair value in the statement of financial position, but for which fair value is required to be disclosed. ASU No. 2011-4 is effective for the first interim or annual period beginning on or after December 15, 2011, or January 1, 2012 for AES. The adoption is not expected to have a material impact on the Company’s financial position, results of operations or cash flows.

2. INVENTORY

The following table summarizes the Company’s inventory balances as of June 30, 2011 and December 31, 2010:

 

     June 30,
2011
     December 31,
2010
 
     (in millions)  

Coal, fuel oil and other raw materials

   $ 351      $ 276  

Spare parts and supplies

     303        286  
  

 

 

    

 

 

 

Total

   $         654      $         562  
  

 

 

    

 

 

 

3. FAIR VALUE DISCLOSURES

The fair value of current financial assets and liabilities, debt service reserves and other deposits approximate their reported carrying amounts. The fair value of non-recourse debt is estimated based upon the type of loan. For variable rate loans, carrying value approximates fair value. For fixed rate loans, the fair value is estimated using quoted market prices or discounted cash flow analyses. See Note 8 — Debt for additional information on the fair value and carrying value of debt. The fair value of interest rate swap, cap and floor agreements, foreign currency forwards, swaps and options and energy derivatives is the estimated net amount that the Company would receive or pay to sell or transfer the agreements as of the balance sheet date.

The estimated fair values of the Company’s assets and liabilities have been determined using available market information. By virtue of these amounts being estimates and based on hypothetical transactions to sell assets or transfer liabilities, the use of different market assumptions and/or estimation methodologies may have a material effect on the estimated fair value amounts.

 

7


Table of Contents

The following table summarizes the carrying amount and fair value of certain of the Company’s financial assets and liabilities as of June 30, 2011 and December 31, 2010:

 

     June 30, 2011      December 31, 2010  
      Carrying
Amount
     Fair
Value
     Carrying
Amount
     Fair
Value
 
     (in millions)  

Assets

           

Marketable securities

   $ 1,271      $ 1,271       $ 1,772      $ 1,772   

Derivatives

     155        155         124        124   
  

 

 

    

 

 

    

 

 

    

 

 

 

Total assets

   $ 1,426      $ 1,426       $ 1,896      $ 1,896   
  

 

 

    

 

 

    

 

 

    

 

 

 

Liabilities

           

Debt

   $ 21,435      $ 22,179       $ 19,551      $ 20,137   

Derivatives

     440        440         423        423   
  

 

 

    

 

 

    

 

 

    

 

 

 

Total liabilities

   $ 21,875      $ 22,619       $ 19,974      $ 20,560   
  

 

 

    

 

 

    

 

 

    

 

 

 

Valuation Techniques:

The fair value measurement accounting guidance describes three main approaches to measuring the fair value of assets and liabilities: (1) market approach; (2) income approach and (3) cost approach. The market approach uses prices and other relevant information generated from market transactions involving identical or comparable assets or liabilities. The income approach uses valuation techniques to convert future amounts to a single present value amount. The measurement is based on current market expectations of the return on those future amounts. The cost approach is based on the amount that would currently be required to replace an asset. The Company measures its investments and derivatives at fair value on a recurring basis. Additionally, in connection with annual or event-driven impairment evaluations, certain nonfinancial assets and liabilities are measured at fair value on a nonrecurring basis. These include long-lived tangible assets (i.e., property, plant and equipment), goodwill and intangible assets (e.g., sales concessions, land use rights and emissions allowances etc). In general, the Company determines the fair value of investments and derivatives using the market approach and the income approach, respectively. In the nonrecurring measurements of nonfinancial assets and liabilities, all three approaches are considered; however, fair value generated by the income approach is often selected.

Investments

The Company’s investments measured at fair value generally consist of marketable debt and equity securities. Equity securities are measured at fair value using quoted market prices. Debt securities primarily consist of unsecured debentures, certificates of deposit and government debt securities held by our Brazilian subsidiaries. Returns and pricing on these instruments are generally indexed to the CDI (Brazilian equivalent to London Inter-Bank Offered Rate, or LIBOR, a benchmark interest rate widely used by banks in the interbank lending market) or Selic (overnight borrowing rate) rates in Brazil. Fair value is determined from comparisons to market data obtained for similar assets and are considered Level 2 in the fair value hierarchy. For more detail regarding the fair value of investments see Note 4 — Investments in Marketable Securities.

Derivatives

When deemed appropriate, the Company manages its risk from interest and foreign currency exchange rate and commodity price fluctuations through the use of over-the-counter financial and physical derivative instruments. The derivatives are primarily interest rate swaps to hedge non-recourse debt to establish a fixed rate on variable rate debt, foreign exchange instruments to hedge against currency fluctuations, commodity derivatives to hedge against commodity price fluctuations and embedded derivatives associated with commodity contracts. The Company’s subsidiaries are counterparties to various over-the-counter derivatives, which include

 

8


Table of Contents

interest rate swaps and options, foreign currency options and forwards and commodity swaps. In addition, the Company’s subsidiaries are counterparties to certain power purchase agreements (“PPAs”) and fuel supply agreements that are derivatives or include embedded derivatives.

For the derivatives where there is a standard industry valuation model, the Company uses that model to estimate the fair value. For the derivatives (such PPAs and fuel supply agreements that are derivatives or include embedded derivatives) where there is not a standard industry valuation model, the Company has created internal valuation models to estimate the fair value, using observable data to the extent available. For all derivatives, the income approach is used, which consists of forecasting future cash flows based on contractual notional amounts and applicable and available market data as of the valuation date. The following are among the most common market data inputs used in the income approach: volatilities, spot and forward benchmark interest rates (such as LIBOR and Euro Inter Bank Offered Rate (“EURIBOR”)), foreign exchange rates and commodity prices. Forward rates and prices are generally obtained from published information provided by pricing services for an instrument with the same duration as the derivative instrument being valued. In situations where significant inputs are not observable, the Company uses relevant techniques to best estimate the inputs, such as regression analysis, Monte Carlo simulation or prices for similarly traded instruments available in the market.

For each derivative, the income approach is used to estimate the cash flows over the remaining term of the contract. Those cash flows are then discounted using the relevant spot benchmark interest rate (such as LIBOR or EURIBOR) plus a spread that reflects the credit or nonperformance risk. This risk is estimated by the Company using credit spreads and risk premiums that are observable in the market, whenever possible, or estimated borrowing costs based on bank quotes, industry publications and/or information on financing closed on similar projects. To the extent that management can estimate the fair value of these assets or liabilities without the use of significant unobservable inputs, these derivatives are classified as Level 2.

In certain instances, the published forward rates or prices may not extend through the remaining term of the contract and management must make assumptions to extrapolate the curve, which necessitates the use of unobservable inputs, such as proxy commodity prices or historical settlements to forecast forward prices. In addition, in certain instances, there may not be third party data readily available which requires the use of unobservable inputs. Similarly, in certain instances, the spread that reflects the credit or nonperformance risk is unobservable. The fair value hierarchy of an asset or a liability is based on the level of significance of the input assumptions. An input assumption is considered significant if it affects the fair value by at least 10%. Assets and liabilities are transferred to Level 3 when the use of unobservable inputs becomes significant. Similarly, when the use of unobservable input becomes insignificant for Level 3 assets and liabilities, they are transferred to Level 2.

Transfers in and out of Level 3 are determined as of the end of the reporting period and are from and to Level 2. The Company has not had any Level 1 derivatives so there have not been any transfers between Levels 1 and 2.

Nonfinancial Assets and Liabilities

For nonrecurring measurements derived using the income approach, fair value is determined using valuation models based on the principles of discounted cash flows (“DCF”). The income approach is most often used in the impairment evaluation of long-lived tangible assets, goodwill and intangible assets. The Company has developed internal valuation models for such valuations; however, an independent valuation firm may be engaged in certain situations. In such situations, the independent valuation firm largely uses DCF valuation models as the primary measure of fair value though other valuation approaches are also considered. A few examples of input assumptions to such valuations include macroeconomic factors such as growth rates, industry demand, inflation, exchange rates and power and commodity prices. Whenever possible, the Company attempts to obtain market observable data to develop input assumptions. Where the use of market observable data is limited or not possible for certain input assumptions, the Company develops its own estimates using a variety of techniques such as regression analysis and extrapolations.

 

9


Table of Contents

For nonrecurring measurements derived using the market approach, recent market transactions involving the sale of identical or similar assets are considered. The use of this approach is limited because it is often difficult to find sale transactions of identical or similar assets. This approach is used in the impairment evaluations of certain intangible assets. Otherwise, it is used to corroborate the fair value determined under the income approach.

For nonrecurring measurements derived using the cost approach, fair value is typically determined using the replacement cost approach. Under this approach, the depreciated replacement cost of assets is determined by first determining the current replacement cost of assets and then applying the remaining useful life percentages to such cost. Further adjustments for economic and functional obsolescence are made to the depreciated replacement cost. This approach involves a considerable amount of judgment which is why its use is limited to the measurement of a few long-lived tangible assets. Like the market approach, this approach is also used to corroborate the fair value determined under the income approach. For the six months ended June 30, 2011, the Company did not measure any nonfinancial assets under the cost approach.

Fair Value Considerations:

In determining fair value, the Company considers the source of observable market data inputs, liquidity of the instrument, the credit risk of the counterparty and the risk of the Company’s or its counterparty’s nonperformance. The conditions and criteria used to assess these factors are:

Sources of market assumptions

The Company derives most of its market assumptions from market efficient data sources (e.g., Bloomberg and Platt’s). To determine fair value, where market data is not readily available, management uses comparable market sources and empirical evidence to develop its own estimates of market assumptions.

Market liquidity

The Company evaluates market liquidity based on whether the financial or physical instrument, or the underlying asset, is traded in an active or inactive market. An active market exists if the prices are fully transparent to market participants, can be measured by market bid and ask quotes, the market has a relatively large proportion of trading volume as compared to the Company’s current trading volume and the market has a significant number of market participants that will allow the market to rapidly absorb the quantity of the assets traded without significantly affecting the market price. Another factor the Company considers when determining whether a market is active or inactive is the presence of government or regulatory controls over pricing that could make it difficult to establish a market based price when entering into a transaction.

Nonperformance risk

Nonperformance risk refers to the risk that the obligation will not be fulfilled and affects the value at which a liability is transferred or an asset is sold. Nonperformance risk includes, but may not be limited to, the Company or counterparty’s credit and settlement risk. Nonperformance risk adjustments are dependent on credit spreads, letters of credit, collateral, other arrangements available and the nature of master netting arrangements. The Company and its subsidiaries are parties to various interest rate swaps and options; foreign currency options and forwards; and derivatives and embedded derivatives which subject the Company to nonperformance risk. The financial and physical instruments held at the subsidiary level are generally non-recourse to the Parent Company.

Nonperformance risk on the investments held by the Company is incorporated in the fair value derived from quoted market data to mark the investments to fair value.

 

10


Table of Contents

The Company adjusts for nonperformance or credit risk on its derivative instruments by deducting a credit valuation adjustment (“CVA”). The CVA is based on the margin or debt spread of the Company’s subsidiary or counterparty and the tenor of the respective derivative instrument. The counterparty for a derivative asset position is considered to be the bank or government sponsored banking entity or counterparty to the PPA or commodity contract. The CVA for asset positions is based on the counterparty’s credit ratings and debt spreads or, in the absence of readily obtainable credit information, the respective country debt spreads are used as a proxy. The CVA for liability positions is based on the Parent Company’s or the subsidiary’s current debt spread, the margin on indicative financing arrangements, or in the absence of readily obtainable credit information, the respective country debt spreads are used as a proxy. All derivative instruments are analyzed individually and are subject to unique risk exposures.

Recurring Measurements

The following table sets forth, by level within the fair value hierarchy, the Company’s financial assets and liabilities that were measured at fair value on a recurring basis as of June 30, 2011 and December 31, 2010. Financial assets and liabilities have been classified in their entirety based on the lowest level of input that is significant to the fair value measurement. The Company’s assessment of the significance of a particular input to the fair value measurement requires judgment, and may affect the determination of the fair value of the assets and liabilities and their placement within the fair value hierarchy levels.

 

     Quoted Market
Prices in Active
Market for

Identical Assets
(Level 1)
     Significant
Other
Observable
Inputs

(Level 2)
     Significant
Unobservable
Inputs

(Level 3)
     Total June 30,
2011
 
     (in millions)  

Assets

           

Available-for-sale securities

   $ 2      $ 1,217      $ 40      $ 1,259  

Trading securities

     12        -         -         12  

Derivatives

     -         72        83        155  
  

 

 

    

 

 

    

 

 

    

 

 

 

Total assets

   $ 14      $ 1,289      $ 123      $ 1,426  
  

 

 

    

 

 

    

 

 

    

 

 

 

Liabilities

           

Derivatives

   $ -       $ 367      $ 73      $ 440  
  

 

 

    

 

 

    

 

 

    

 

 

 

Total liabilities

   $                 -       $             367      $             73      $             440  
  

 

 

    

 

 

    

 

 

    

 

 

 
     Quoted Market
Prices in Active
Market for
Identical Assets
(Level 1)
     Significant
Other
Observable
Inputs

(Level 2)
     Significant
Unobservable
Inputs

(Level 3)
     Total
December 31,
2010
 
     (in millions)  

Assets

           

Available-for-sale securities

   $ 8      $ 1,712      $ 42      $ 1,762  

Trading securities

     10        -         -         10  

Derivatives

     -         63        61        124  
  

 

 

    

 

 

    

 

 

    

 

 

 

Total assets

   $ 18      $ 1,775      $ 103      $ 1,896  
  

 

 

    

 

 

    

 

 

    

 

 

 

Liabilities

           

Derivatives

   $ -       $ 411      $ 12      $ 423  
  

 

 

    

 

 

    

 

 

    

 

 

 

Total liabilities

   $                   -       $             411      $             12      $             423  
  

 

 

    

 

 

    

 

 

    

 

 

 

 

11


Table of Contents

The following tables present a reconciliation of derivative assets and liabilities measured at fair value on a recurring basis using significant unobservable inputs (Level 3) for the three and six months ended June 30, 2011 and 2010 (presented net by type of derivative):

 

     Three Months Ended June 30, 2011  
     Interest
Rate
    Cross
Currency
    Foreign
Currency
    Commodity
and Other
    Total  
    (in millions)  

Balance at April 1

  $ (7   $ 5     $ 23     $ 24     $ 45  

Total gains (losses) (realized and unrealized):

         

Included in earnings (1)

    -        (2     18       (16     -   

Included in other comprehensive income

    (12     8       -        -        (4

Included in regulatory assets

    -        -        -        7       7  

Settlements

    1       4       (1     -        4  

Transfers of assets (liabilities) into Level 3 (2)

    (58     -        -        -        (58

Transfers of (assets) liabilities out of Level 3 (2)

    16       -        (2     2       16  
 

 

 

   

 

 

   

 

 

   

 

 

   

 

 

 

Balance at June 30

  $     (60   $     15     $     38     $     17     $ 10  
 

 

 

   

 

 

   

 

 

   

 

 

   

 

 

 

Total gains/(losses) for the period included in earnings attributable to the change in unrealized gains/(losses) relating to assets and liabilities held at the end of the period

  $ -      $ (2   $ 15     $ (7   $ 6  
 

 

 

   

 

 

   

 

 

   

 

 

   

 

 

 
     Three Months Ended June 30, 2010  
     Interest
Rate
    Cross
Currency
    Foreign
Currency
    Commodity
and Other
    Total  
    (in millions)  

Balance at April 1

  $ (18   $ (7   $ (1   $ 19     $ (7

Total gains (losses) (realized and unrealized):

         

Included in earnings (1)

    1       (1     22       1       23  

Included in other comprehensive income

    (12     (28     -        -        (40

Included in regulatory assets

    (2     -        -        4       2  

Settlements

    2       2       -        (5     (1

Transfers of assets (liabilities) into Level 3 (2)

    (209     -        (3     -        (212

Transfers of (assets) liabilities out of Level 3 (2)

    12       -        -        -        12  
 

 

 

   

 

 

   

 

 

   

 

 

   

 

 

 

Balance at June 30

  $     (226   $     (34   $ 18     $ 19     $ (223
 

 

 

   

 

 

   

 

 

   

 

 

   

 

 

 

Total gains/(losses) for the period included in earnings attributable to the change in unrealized gains/(losses) relating to assets and liabilities held at the end of the period

  $ (1   $ (1   $ 20     $ (6   $         12  
 

 

 

   

 

 

   

 

 

   

 

 

   

 

 

 
     Six Months Ended June 30, 2011  
     Interest
Rate
    Cross
Currency
    Foreign
Currency
    Commodity
and Other
    Total  
    (in millions)  

Balance at January 1

  $ (1   $ 10     $ 22     $ 18     $ 49  

Total gains (losses) (realized and unrealized):

         

Included in earnings (1)

    -        -        18       (7     11  

Included in other comprehensive income

    (1     -        -        -        (1

Included in regulatory assets

    -        -        -        6       6  

Settlements

    -        5       (2     -        3  

Transfers of assets (liabilities) into Level 3 (2)

    (58     -        -        -        (58

Transfers of (assets) liabilities out of Level 3 (2)

    -        -        -        -        -   
 

 

 

   

 

 

   

 

 

   

 

 

   

 

 

 

Balance at June 30

  $ (60   $ 15     $ 38     $ 17     $ 10  
 

 

 

   

 

 

   

 

 

   

 

 

   

 

 

 

Total gains/(losses) for the period included in earnings attributable to the change in unrealized gains/(losses) relating to assets and liabilities held at the end of the period

  $ -      $ -      $ 15     $ (1   $ 14  
 

 

 

   

 

 

   

 

 

   

 

 

   

 

 

 

 

12


Table of Contents
    Six Months Ended June 30, 2010  
    Interest
Rate
    Cross
Currency
    Foreign
Currency
    Commodity
and Other
    Total  
    (in millions)  

Balance at January 1

  $ (12   $ (12   $ -      $ 24     $ -   

Total gains (losses) (realized and unrealized):

         

Included in earnings(1)

    -        5       22       4       31  

Included in other comprehensive income

    (12     (30     -        -        (42

Included in regulatory assets

    (2     -        -        3       1  

Settlements

    3       3       -        (12     (6

Transfers of assets (liabilities) into Level 3 (2)

    (214     -        (4     -        (218

Transfers of (assets) liabilities out of Level 3 (2)

    11       -        -        -        11  
 

 

 

   

 

 

   

 

 

   

 

 

   

 

 

 

Balance at June 30

  $     (226   $ (34   $ 18     $       19     $ (223
 

 

 

   

 

 

   

 

 

   

 

 

   

 

 

 

Total gains/(losses) for the period included in earnings attributable to the change in unrealized gains/(losses) relating to assets and liabilities held at the end of the period

  $ (1   $       5     $     20     $ (10   $       14  
 

 

 

   

 

 

   

 

 

   

 

 

   

 

 

 

 

(1) 

The gains (losses) included in earnings for these Level 3 derivatives are classified as follows: interest rate and cross currency derivatives as interest expense, foreign currency derivatives as foreign currency transaction gains (losses) and commodity and other derivatives as either non-regulated revenue, non-regulated cost of sales, or other expense. See Note 5 — Derivative Instruments and Hedging Activities for further information regarding the classification of gains and losses included in earnings in the condensed consolidated statements of operations.

(2) 

Transfers in and out of Level 3 are determined as of the end of the reporting period and are from and to Level 2, as the Company has no Level 1 derivative assets or liabilities. The (assets) liabilities transferred out of Level 3 are primarily the result of a decrease in the significance of unobservable inputs used to calculate the credit valuation adjustments of these derivative instruments. Similarly, the assets (liabilities) transferred into Level 3 are primarily the result of an increase in the significance of unobservable inputs used to calculate the credit valuation adjustments of these derivative instruments.

The following table presents a reconciliation of available-for-sale securities measured at fair value on a recurring basis using significant unobservable inputs (Level 3) for the three and six months ended June 30, 2011 and 2010:

 

      Three Months Ended
June 30,
     Six Months Ended
June 30,
 
      2011      2010      2011     2010  
     (in millions)  

Balance at beginning of period(1)

   $ 40      $ 42      $ 42     $ 42  

Settlements

     -         -         (2     -   
  

 

 

    

 

 

    

 

 

   

 

 

 

Balance at June 30

   $     40      $     42      $     40     $     42  
  

 

 

    

 

 

    

 

 

   

 

 

 

Total gains/(losses) for the period included in earnings attributable to the change in unrealized gains/losses relating to assets held at the end of the period

   $ -       $ -       $ -      $ -   
  

 

 

    

 

 

    

 

 

   

 

 

 

 

(1) 

Available-for-sale securities in Level 3 are auction rate securities and variable rate demand notes which have failed remarketing or are not actively trading and for which there are no longer adequate observable inputs available to measure the fair value.

Long-lived Assets Held and Used

The Company has continued to evaluate the recoverability of our long-lived assets at Kelanitissa, our diesel-fired plant in Sri Lanka. During the quarter, the Company determined the long-lived assets at Kelanitissa were impaired. The long-lived assets with a carrying amount of $66 million were written down to their estimated fair value of $33 million based on a discounted cash flow analysis. This resulted in the recognition of asset impairment expense of $33 million for the three months ended June 30, 2011, see Note 14 — Impairments for further information.

 

13


Table of Contents

4. INVESTMENTS IN MARKETABLE SECURITIES

The following table sets forth the Company’s investments in marketable debt and equity securities as of June 30, 2011 and December 31, 2010 by security class and by level within the fair value hierarchy. The security classes are determined based on the nature and risk of a security and are consistent with how the Company manages, monitors and measures its marketable securities.

 

      June 30, 2011      December 31, 2010  
      Level 1      Level 2      Level 3      Total      Level 1      Level 2      Level 3      Total  
     (in millions)  

AVAILABLE-FOR-SALE:(1)

                       

Debt securities:

                       

Unsecured debentures(2)

   $ -       $ 566      $ -       $ 566      $ -       $ 727      $ -       $ 727  

Certificates of deposit(2)

     -         537        -         537        -         877        -         877  

Government debt securities

     -         46        -         46        -         47        -         47  

Other debt securities

     -         -         40        40        -         -         42        42  
  

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

 

Subtotal

     -         1,149        40        1,189        -         1,651        42        1,693  

Equity securities:

                       

Mutual funds

     -         68        -         68        1        61        -         62  

Common stock

     2        -         -         2        7        -         -         7  
  

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

 

Subtotal

     2        68        -         70        8        61        -         69  
  

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

 

Total available-for-sale

     2        1,217        40        1,259        8        1,712        42      $ 1,762  
  

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

 

TRADING:

                       

Equity securities:

                       

Mutual funds

     12        -         -         12        10        -         -         10  
  

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

 

Total trading

     12        -         -         12        10        -         -         10  
  

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

 

TOTAL

   $ 14      $ 1,217      $ 40      $ 1,271      $ 18      $ 1,712      $ 42      $ 1,772  
  

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

 

 

(1) 

Cost/amortized cost approximated fair value at June 30, 2011 and December 31, 2010, with the exception of certain common stock investments with a cost basis and fair value of $4 million and $2 million, respectively, at June 30, 2011, and a cost basis and fair value of $6 million and $7 million, respectively, at December 31, 2010.

(2) 

Unsecured debentures are instruments similar to certificates of deposit that are held primarily by our subsidiaries in Brazil. The unsecured debentures and certificates of deposit included here do not qualify as cash equivalents, but meet the definition of a security under the relevant guidance and are therefore classified as available-for-sale securities.

As of June 30, 2011, all available-for-sale debt securities had stated maturities within one year, with the exception of $40 million of variable rate demand notes held by IPL. These securities, classified as other debt securities in the table above, had stated maturities of greater than ten years.

 

14


Table of Contents

The following table summarizes the pre-tax gains and losses related to available-for-sale and trading securities for the three and six months ended June 30, 2011 and 2010. Gains and losses on the sale of investments are determined using the specific identification method. For the three and six months ended June 30, 2011 and 2010, there were no realized losses on the sale of available-for-sale securities and no other-than-temporary impairment of marketable securities recognized in earnings or other comprehensive income.

 

     Three Months Ended
June 30,
    Six Months Ended
June 30,
 
     2011     2010     2011     2010  
     (in millions)     (in millions)  

Gains included in earnings that relate to trading securities held at the reporting date

   $ -      $ 1     $ 1     $ 1  

Unrealized losses on available-for-sale securities included in other comprehensive income

   $ (1   $ (3   $ (3   $ (10

Proceeds from sales of available-for-sale securities

   $     1,867     $     2,247     $     3,124     $     3,210  

Gross realized gains on sales

   $ 3     $ 1     $ 4     $ 1  

5. DERIVATIVE INSTRUMENTS AND HEDGING ACTIVITIES

Risk Management Objectives

The Company is exposed to market risks associated with its enterprise-wide business activities, namely the purchase and sale of fuel and electricity as well as foreign currency risk and interest rate risk. In order to manage the market risks associated with these business activities, we enter into contracts that incorporate derivatives and financial instruments, including forwards, futures, options, swaps or combinations thereof, as appropriate. The Company generally applies hedge accounting to contracts as long as they are eligible under the accounting standards for derivatives and hedging. While derivative transactions are not entered into for trading purposes, some contracts are not eligible for hedge accounting.

Interest Rate Risk

AES and its subsidiaries utilize variable rate debt financing for construction projects and operations, resulting in an exposure to interest rate risk. Interest rate swap, cap and floor agreements are entered into to manage interest rate risk by effectively fixing or limiting the interest rate exposure on the underlying financing. These interest rate contracts range in maturity through 2030, and are typically designated as cash flow hedges. The following table sets forth, by underlying type of interest rate index, the Company’s current and maximum outstanding notional under its interest rate derivative instruments, the weighted average remaining term and the percentage of variable-rate debt hedged that is based on the related index as of June 30, 2011 regardless of whether the derivative instruments are in qualifying cash flow hedging relationships:

 

     June 30, 2011  
     Current      Maximum(1)              

Interest Rate Derivatives

   Derivative
Notional
     Derivative
Notional
Translated
to USD
     Derivative
Notional
     Derivative
Notional
Translated
to USD
    Weighted
Average
Remaining
Term(1)
    % of  Debt
Currently
Hedged
by Index(2)
 
            (in millions)            (in years)        

Libor (U.S. Dollar)

     3,282      $     3,282        3,609      $     3,609        9        72

Euribor (Euro)

     1,074        1,558        1,074        1,558        13        65

Libor (British Pound Sterling)

     28        45        42        68        17        47

Securities Industry and Financial

               

Markets Association Municipal

               

Swap Index (U.S. Dollar)

     40        40        40        40        12        N/A (3) 

 

(1) 

The Company’s interest rate derivative instruments primarily include accreting and amortizing notionals. The maximum derivative notional represents the largest notional at any point between June 30, 2011 and the

 

15


Table of Contents
  maturity of the derivative instrument, which includes forward starting derivative instruments. The weighted average remaining term represents the remaining tenor of our interest rate derivatives weighted by the corresponding maximum notional.
(2) 

Excludes variable-rate debt tied to other indices where the Company has no interest rate derivatives.

(3) 

The debt that was being hedged is no longer exposed to variable interest payments because it is now held on IPL’s behalf and no longer bears interest.

Cross currency swaps are utilized in certain instances to manage the risk related to fluctuations in both interest rates and certain foreign currencies. These cross currency contracts range in maturity through 2028. The following table sets forth, by type of foreign currency denomination, the Company’s outstanding notional amount under its cross currency derivative instruments as of June 30, 2011, which are all in qualifying cash flow hedge relationships. These swaps are amortizing and therefore the notional amount represents the maximum outstanding notional amount as of June 30, 2011:

 

     June 30, 2011  

Cross Currency Swaps

   Notional      Notional Translated
to USD
     Weighted Average
Remaining Term(1)
     % of Debt Currently
Hedged by Index(2)
 
     (in millions)      (in years)         

Chilean Unidad de Fomento (CLF)

     6      $                     262         15         82

 

(1) 

Represents the remaining tenor of our cross currency swaps weighted by the corresponding notional.

(2) 

Represents the proportion of foreign currency denominated debt hedged by the same foreign currency denominated notional of the cross currency swap.

Foreign Currency Risk

We are exposed to foreign currency risk as a result of our investments in foreign subsidiaries and affiliates. AES operates businesses in many foreign environments and such operations in foreign countries may be impacted by significant fluctuations in foreign currency exchange rates. Foreign currency options and forwards are utilized, where deemed appropriate, to manage the risk related to fluctuations in certain foreign currencies. These foreign currency contracts range in maturity through 2012. The following tables set forth, by type of foreign currency denomination, the Company’s outstanding notional amounts over the remaining terms of its foreign currency derivative instruments as of June 30, 2011 regardless of whether the derivative instruments are in qualifying hedging relationships:

 

     June 30, 2011  

Foreign Currency Options

   Notional      Notional Translated
to USD(1)
    Probability  Adjusted
Notional(2)
    Weighted Average
Remaining Term(3)
 
     (in millions)           (in years)  

Brazilian Real (BRL)

     268      $       164      $       52        <1   

Euro (EUR)

     40        57        27        <1   

 

(1) 

Represents contractual notionals at inception of trade.

(2) 

Represents the gross notional amounts times the probability of exercising the option, which is based on the relationship of changes in the option value with respect to changes in the price of the underlying currency.

(3) 

Represents the remaining tenor of our foreign currency options weighted by the corresponding notional.

 

     June 30, 2011  

Foreign Currency Forwards

   Notional      Notional Translated
to USD
     Weighted Average
Remaining Term(1)
 
     (in millions)      (in years)  

Chilean Peso (CLP)

     87,779      $       181        <1   

Colombian Peso (COP)

     137,110        75        <1   

British Pound (GBP)

     18        31        1   

Argentine Peso (ARS)

     90        20        1   

Philippine Peso (PHP)

     170        4        <1   

 

  (1) 

Represents the remaining tenor of our foreign currency forwards weighted by the corresponding notional.

 

16


Table of Contents

In addition, certain of our subsidiaries have entered into contracts which contain embedded derivatives that require separate valuation and accounting due to the fact that the item being purchased or sold is denominated in a currency other than the functional currency of that subsidiary or the currency of the item. These contracts range in maturity through 2025. The following table sets forth, by type of foreign currency denomination, the Company’s outstanding notional over the remaining terms of its foreign currency embedded derivative instruments as of June 30, 2011:

 

     June 30, 2011  

Embedded Foreign Currency Derivatives

   Notional      Notional Translated
to USD
     Weighted Average
Remaining Term(1)
 
     (in millions)      (in years)  

Philippine Peso (PHP)

     18,048      $       416        3   

Kazakhstani Tenge (KZT)

     31,358        215        9   

Argentine Peso (ARS)

     795        193        11   

Hungarian Forint (HUF)

     17,819        97        1   

Euro (EUR)

     22        32        2   

Brazilian Real (BRL)

     8        5        1   

Cameroon Franc (XAF)

     352        1        2   

 

  (1) 

Represents the remaining tenor of our foreign currency embedded derivatives weighted by the corresponding notional.

Commodity Price Risk

We are exposed to the impact of market fluctuations in the price of electricity, fuel and environmental credits. Although we primarily consist of businesses with long-term contracts or retail sales concessions (which provide our distribution businesses with a franchise to serve a specific geographic region), a portion of our current and expected future revenues are derived from businesses without significant long-term purchase or sales contracts. These businesses subject our results of operations to the volatility of prices for electricity, fuel and environmental credits in competitive markets. We have used a hedging strategy, where appropriate, to hedge our financial performance against the effects of fluctuations in energy commodity prices. The implementation of this strategy can involve the use of PPAs, fuel supply agreements, commodity forward contracts, futures, swaps and options. Some of our businesses hedge certain aspects of their commodity risks using financial hedging instruments.

The PPAs and fuel supply agreements entered into by the Company are evaluated to determine if they meet the definition of a derivative or contain embedded derivatives, either of which requires separate valuation and accounting. To be a derivative under the accounting standards for derivatives and hedging, an agreement would need to have a notional and an underlying, require little or no initial net investment and could be net settled. Generally, these agreements do not meet the definition of a derivative, often due to the inability to be net settled. On a quarterly basis, we evaluate the markets for the commodities to be delivered under these agreements to determine if facts and circumstances have changed such that the agreements could then be net settled and meet the definition of a derivative.

 

17


Table of Contents

Nonetheless, certain of the PPAs and fuel supply agreements entered into by certain of the Company’s subsidiaries are derivatives or contain embedded derivatives requiring separate valuation and accounting. These contracts range in maturity through 2024. The following table sets forth, by type of commodity, the Company’s outstanding notionals for the remaining term of its commodity derivatives and embedded derivative instruments as of June 30, 2011:

 

     June 30, 2011  

Commodity Derivatives

   Notional     Weighted  Average
Remaining Term(1)
 
     (in millions)     (in years)  

Natural gas (MMBTU)

     34        11   

Petcoke (Metric tons)

     13        13   

Aluminum (MWh)

     17 (2)         9   

 

  (1) 

Represents the remaining tenor of our commodity and embedded derivatives weighted by the corresponding volume.

  (2) 

Our exposure is to fluctuations in the price of aluminum while the notional is based on the amount of power we sell under the PPA.

Accounting and Reporting

The following table sets forth the Company’s derivative instruments as of June 30, 2011 and December 31, 2010 by type of derivative and by level within the fair value hierarchy. Derivative assets and liabilities are recognized at their fair value. Derivative assets and liabilities are combined with other balances and included in the following captions in our condensed consolidated balance sheets: current derivative assets in other current assets, noncurrent derivative assets in other noncurrent assets, current derivative liabilities in accrued and other liabilities (except for one in non-recourse debt-current) and long-term derivative liabilities in other long-term liabilities.

 

     June 30, 2011      December 31, 2010  
     Level 1      Level 2      Level 3      Total      Level 1      Level 2      Level 3      Total  
     (in millions)      (in millions)  

Assets

                       

Current assets:

                       

Interest rate derivatives

   $         -       $ 6      $ -       $ 6      $ -       $ -       $ -       $ -   

Foreign currency derivatives

     -         14        4        18        -         4        3        7  

Commodity and other derivatives

     -         4        9        13        -         2        3        5  
  

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

 

Total current assets

     -         24        13        37        -         6        6        12  
  

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

 

Noncurrent assets:

                       

Interest rate derivatives

     -         37        -         37        -         49        -         49  

Foreign currency derivatives

     -         5        41        46        -         4        27        31  

Cross currency derivatives

     -         -         20        20        -         -         12        12  

Commodity and other derivatives

     -         6        9        15        -         4        16        20  
  

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

 

Total noncurrent assets

     -         48        70        118        -         57        55        112  
  

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

 

Total assets

   $ -       $ 72      $     83      $     155      $         -       $ 63      $     61      $     124  
  

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

 

Liabilities

                       

Current liabilities:

                       

Interest rate derivatives

   $ -       $     135      $ 13      $ 148      $ -       $     137      $ -       $ 137  

Cross currency derivatives

     -         -         5        5        -         -         2        2  

Foreign currency derivatives

     -         11        1        12        -         13        -         13  

Commodity and other derivatives

     -         4        -         4        -         -         -         -   
  

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

 

Total current liabilities

     -         150        19        169        -         150        2        152  
  

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

 

Long-term liabilities:

                       

Interest rate derivatives

     -         203        47        250        -         246        1        247  

Foreign currency derivatives

     -         12        6        18        -         15        8        23  

Commodity and other derivatives

     -         2        1        3        -         -         1        1  
  

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

 

Total long-term liabilities

     -         217        54        271        -         261        10        271  
  

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

 

Total liabilities

   $ -       $ 367      $ 73      $ 440      $ -       $ 411      $ 12      $ 423  
  

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

 

 

18


Table of Contents

The following table sets forth the fair value and balance sheet classification of derivative instruments as of June 30, 2011 and December 31, 2010:

 

     June 30, 2011      December 31, 2010  
     Designated
as Hedging
Instruments
     Not Designated
as Hedging
Instruments
     Total      Designated as
Hedging
Instruments
     Not Designated
as Hedging
Instruments
     Total  
     (in millions)      (in millions)  

Assets

                 

Current assets:

                 

Interest rate derivatives

   $ 6      $ -       $ 6      $ -       $ -       $ -   

Foreign currency derivatives

     1        17        18        -         7        7  

Commodity and other derivatives

     -         13        13        -         5        5  
  

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

 

Total current assets

     7        30        37        -         12        12  
  

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

 

Noncurrent assets:

                 

Interest rate derivatives

     37        -         37        49        -         49  

Foreign currency derivatives

     -         46        46        -         31        31  

Cross currency derivatives

     20        -         20        12        -         12  

Commodity and other derivatives

     -         15        15        -         20        20  
  

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

 

Total noncurrent assets

     57        61        118        61        51        112  
  

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

 

Total assets

   $ 64      $ 91      $ 155      $ 61      $ 63      $ 124  
  

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

 

Liabilities

                 

Current liabilities:

                 

Interest rate derivatives

   $ 141      $ 7      $ 148      $ 126      $ 11      $ 137  

Cross currency derivatives

     5        -         5        2        -         2  

Foreign currency derivatives

     7        5        12        8        5        13  

Commodity and other derivatives

     -         4        4        -         -         -   
  

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

 

Total current liabilities

     153        16        169        136        16        152  
  

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

 

Long-term liabilities:

                 

Interest rate derivatives

     236        14        250        232        15        247  

Foreign currency derivatives

     -         18        18        -         23        23  

Commodity and other derivatives

     -         3        3        -         1        1  
  

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

 

Total long-term liabilities

     236        35        271        232        39        271  
  

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

 

Total liabilities

   $     389      $     51      $     440      $     368      $ 55      $     423  
  

 

 

    

 

 

    

 

 

    

 

 

    

 

 

    

 

 

 

The Company has elected not to offset net derivative positions in the financial statements. Accordingly, the Company does not offset such derivative positions against the fair value of amounts (or amounts that approximate fair value) recognized for the right to reclaim cash collateral (a receivable) or the obligation to return cash collateral (a payable) under master netting arrangements. At June 30, 2011 and December 31, 2010, we held no cash collateral that we received from counterparties to our derivative positions. As we have not received collateral, our derivative assets are exposed to the credit risk of the respective counterparty and, due to this credit risk, the fair value of our derivative assets (as shown in the above two tables) have been reduced by a credit valuation adjustment. Also, at June 30, 2011 and December 31, 2010, we had no cash collateral posted with (held by) counterparties to our derivative positions.

 

19


Table of Contents

The table below sets forth the pre-tax accumulated other comprehensive income (loss) expected to be recognized as an increase (decrease) to income from continuing operations before income taxes over the next twelve months as of June 30, 2011 for the following types of derivatives:

 

     Accumulated
Other Comprehensive
Income (Loss)
 
     (in millions)  

Interest rate derivatives

   $     (108)   

Cross currency derivatives

   $ (4)   

Foreign currency derivatives

   $ (7)   

Commodity and other derivatives

   $ (1)   

The balance in accumulated other comprehensive loss related to derivative transactions will be reclassified into earnings as interest expense is recognized for interest rate hedges and cross currency swaps, as depreciation is recognized for interest rate hedges during construction, and as foreign currency gains and losses are recognized for hedges of foreign currency exposure. These balances are included in the condensed consolidated statements of cash flows as operating and/or investing activities based on the nature of the underlying transaction.

The following tables set forth the gains (losses) recognized in accumulated other comprehensive loss (“AOCL”) and earnings related to the effective portion of derivative instruments in qualifying cash flow hedging relationships, as defined in the accounting standards for derivatives and hedging, for the three and six months ended June 30, 2011 and 2010:

 

     Gains (Losses)
Recognized  in AOCL
         Gains (Losses) Reclassified
from AOCL into Earnings(1)
 
     Three Months
Ended June 30,
   

Classification in Condensed
Consolidated

Statements of Operations

   Three Months
Ended June 30,
 
      2011     2010            2011             2010      
      (in millions)          (in millions)  

Interest rate derivatives

   $ (144   $ (168   Interest expense    $      (27) (2)    $ (29 )(2) 
       Non-regulated cost of sales      (1)        -   
      

Net equity in earnings of affiliates

     (1)        (1 )  

Cross currency derivatives

             11        (26 )     Interest expense             (1 )  

Foreign currency derivatives

     (7 )               7     

Foreign currency transaction gains (losses)

     (2)        -   

Commodity and other derivatives

     (1 )       (12 )     Non-regulated revenue      -        -   
  

 

 

   

 

 

      

 

 

   

 

 

 

Total

   $ (141   $ (199      $ (24 )     $     (31
  

 

 

   

 

 

      

 

 

   

 

 

 

 

      Gains (Losses)
Recognized  in AOCL
         Gains (Losses) Reclassified
from AOCL into Earnings(1)
 
      Six Months Ended
June 30,
   

Classification in Condensed
Consolidated

Statements of Operations

   Six Months Ended
June 30,
 
      2011     2010            2011             2010      
     (in millions)          (in millions)  

Interest rate derivatives

   $ (92   $ (250   Interest expense    $      (53)(2)      $ (57 )(2) 
      

Non-regulated cost of sales

     (2 )       -   
      

Net equity in earnings of affiliates

     (2 )       (2 )  

Cross currency derivatives

     3        (29 )     Interest expense      2        (2 )  

Foreign currency derivatives

     (2 )         7     

Foreign currency transaction gains (losses)

     (4 )       -   
  

 

 

   

 

 

      

 

 

   

 

 

 

Total

   $ (91   $ (272      $ (59   $ (61
  

 

 

   

 

 

      

 

 

   

 

 

 

 

20


Table of Contents

 

(1) 

Excludes $0 million and $8 million related to discontinued operations for the three months ended June 30, 2011 and 2010, respectively, and $0 million and $10 million related to discontinued operations for the six months ended June 30, 2011 and 2010, respectively.

(2) 

Includes amounts that were reclassified from AOCL related to derivative instruments that previously, but no longer, qualify for cash flow hedge accounting.

The following table sets forth the pre-tax gains (losses) recognized in earnings related to the ineffective portion of derivative instruments in qualifying cash flow hedging relationships, as defined in the accounting standards for derivatives and hedging, for the three and six months ended June 30, 2011 and 2010:

 

     

Classification in Condensed

Consolidated Statements of Operations

   Gains (Losses)
Recognized in Earnings
    Gains (Losses)
Recognized in Earnings
 
      Three Months Ended
June 30,
    Six Months Ended
June 30,
 
             2011             2010             2011             2010      
           (in millions)     (in millions)  

Interest rate derivatives

   Interest expense    $ -      $ - (1)   $ (7   $ (8
  

Net equity in earnings of affiliates

     (1 )       (1 )       (1 )       (1 )  

Cross currency derivatives

   Interest expense      (2     (1     (2 )       4   

Foreign currency derivatives

  

Foreign currency transaction gains (losses)

     - (1)      - (1)      - (1)      - (1) 
     

 

 

   

 

 

   

 

 

   

 

 

 

Total

      $         (3   $         (2   $         (10   $         (5
     

 

 

   

 

 

   

 

 

   

 

 

 

 

(1) 

De minimis amount.

The following table sets forth the gains (losses) recognized in earnings related to derivative instruments not designated as hedging instruments under the accounting standards for derivatives and hedging, for the three and six months ended June 30, 2011 and 2010:

 

     

Classification in Condensed
Consolidated Statements of Operations

   Gains (Losses)
Recognized in Earnings
    Gains (Losses)
Recognized in Earnings
 
      Three Months Ended
June 30,
    Six Months Ended
June 30,
 
          2011             2010             2011             2010      
          (in millions)     (in millions)  

Interest rate derivatives

   Interest expense    $ (1 )     $ (1   $ (1 )     $ (5

Foreign exchange derivatives 

  

Foreign currency transaction gains (losses)

     20        (27     27        (25
  

Net equity in earnings of

affiliates

     -        1       -        2   

Commodity and other derivatives

   Non-regulated revenue      (13     4       (9 )       4   
   Non-regulated cost of sales      (2 )       1       (1 )       5   
     

 

 

   

 

 

   

 

 

   

 

 

 

Total

      $ 4      $ (22   $ 16      $ (19
     

 

 

   

 

 

   

 

 

   

 

 

 

In addition, IPL has two derivative instruments for which the gains and losses are accounted for in accordance with accounting standards for regulated operations, as regulatory assets or liabilities. Gains and losses on these derivatives due to changes in the fair value of these derivatives are probable of recovery through future rates and are initially recognized as an adjustment to the regulatory asset or liability and recognized through earnings when the related costs are recovered through IPL’s rates. Therefore, these gains and losses are excluded

 

21


Table of Contents

from the above table. The following table sets forth the change in regulatory assets and liabilities resulting from the change in the fair value of these derivatives for the three and six months ended June 30, 2011 and 2010:

 

     Three Months Ended
June  30,
    Six Months Ended
June  30,
 
     2011     2010     2011     2010  
     (in millions)  

(Increase) decrease in regulatory assets

   $ (2   $ (2   $ (2   $ (1

Increase (decrease) in regulatory liabilities

   $         7     $         5     $         6     $         6  

Credit Risk-Related Contingent Features

Gener, our business in Chile, has cross currency swap agreements with counterparties to swap Chilean inflation indexed bonds issued in December 2007 into U.S. Dollars. The derivative agreements contain credit contingent provisions which would permit the counterparties with which Gener is in a net liability position to require collateral credit support when the fair value of the derivatives exceeds the unsecured thresholds established in the agreement. These thresholds vary based on Gener’s credit rating. If Gener’s credit rating were to fall below the minimum threshold established in the swap agreements, the counterparties can demand immediate collateralization of the entire mark-to-market value of the swaps (excluding credit valuation adjustments) if Gener is in a net liability position. The mark-to-market value of the swaps was in a net asset position at June 30, 2011 and December 31, 2010. As of June 30, 2011 and December 31, 2010, Gener had not posted collateral to support these swaps.

6. INVESTMENTS IN AND ADVANCES TO AFFILIATES

In February 2011, the Company acquired a 49.6% interest in Entek Elektrik Uretim A.S. (“Entek”) for approximately $136 million. Additional consideration of $13 million was provided in May 2011 which resulted in a total purchase price of $149 million as of June 30, 2011. Entek owns and operates two gas-fired generation facilities with an aggregate capacity of 312 MW in Turkey, and is also engaged in an energy trading business. The Company has significant influence, but not control of Entek and accordingly the investment has been accounted for under the equity method of accounting.

7. FINANCING RECEIVABLES

Accounts and notes receivable are carried at amortized cost. The Company periodically assesses the collectability of accounts receivable considering factors such as specific evaluation of collectability, historical collection experience, the age of accounts receivable and other currently available evidence of the collectability, and records an allowance for doubtful accounts for the estimated uncollectable amount as appropriate. Certain of our businesses charge interest on accounts receivable either under contractual terms or where charging interest is a customary business practice. In such cases, interest income is recognized on an accrual basis. In situations where the collection of interest is uncertain, interest income is recognized as cash is received. Individual accounts and notes receivable are written off when they are no longer deemed collectable.

Included in “Noncurrent other assets” on the condensed consolidated balance sheets as of June 30, 2011 and December 31, 2010 are long-term financing receivables of $278 million and $151 million, respectively, primarily with certain Latin American governmental bodies. These receivables have contractual maturities of greater than one year and are being collected in installments as scheduled. Of the total $278 million as of June 30, 2011, amounts of $213 million and $52 million, respectively, relate to our businesses in Argentina and the Dominican Republic. The remaining amounts relate to our distribution businesses in Brazil.

 

22


Table of Contents

8. DEBT

The Company has two types of debt reported on its condensed consolidated balance sheet: non-recourse and recourse debt. Non-recourse debt is used to fund investments and capital expenditures for the construction and acquisition of electric power plants, wind projects, distribution companies and other project-related investments at our subsidiaries. Non-recourse debt is generally secured by the capital stock, physical assets, contracts and cash flows of the related subsidiary. Absent guarantees, intercompany loans or other credit support, the default risk is limited to the respective business and is without recourse to the Parent Company and other subsidiaries, though the Company’s equity investments and/or subordinated loans to projects (if any) are at risk. Recourse debt is direct borrowings by the Parent Company and is used to fund development, construction or acquisitions, including serving as funding for equity investments or loans to the affiliates. The Parent Company’s debt is, among other things, recourse to the Parent Company and is structurally subordinated to the affiliates’ debt.

The following table summarizes the carrying amount and estimated fair values of the Company’s recourse and non-recourse debt as of June 30, 2011 and December 31, 2010:

 

     June 30, 2011      December 31, 2010  
     Carrying
Amount
     Fair Value      Carrying
Amount
     Fair Value  
     (in millions)  

Non-recourse debt

   $ 15,242      $ 15,648      $ 14,939      $ 15,269  

Recourse debt

     6,193        6,531        4,612        4,868  
  

 

 

    

 

 

    

 

 

    

 

 

 

Total debt

   $ 21,435      $ 22,179      $ 19,551      $ 20,137  
  

 

 

    

 

 

    

 

 

    

 

 

 

Recourse and non-recourse debt are carried at amortized cost. The fair value of recourse debt is estimated based on quoted market prices. The fair value of non-recourse debt is estimated differently based upon the type of loan. The fair value of fixed rate loans is estimated using quoted market prices, if available, or a discounted cash flow analysis. In the discounted cash flow analysis, the discount rate is based on the credit rating of the individual debt instruments if available, or the credit rating of the subsidiary. If the subsidiary’s credit rating is not available, a synthetic credit rating is determined using certain key metrics, including cash flow ratios and interest coverage, as well as other industry specific factors. For subsidiaries located outside the U.S., in the event that the country rating is lower than the credit rating previously determined, the country rating is used for the purposes of the discounted cash flow analysis. The fair value of recourse and non-recourse debt excludes accrued interest at the valuation date.

The fair value was determined using available market information as of June 30, 2011. The Company is not aware of any factors that would significantly affect the fair value amounts subsequent to June 30, 2011.

Non-Recourse Debt

The following table summarizes the Company’s subsidiary non-recourse debt in default or accelerated as of June 30, 2011 and is in the current portion of non-recourse debt unless otherwise indicated:

 

Subsidiary

   Primary Nature
of  Default
     June 30, 2011  
      Default Amount      Net Assets  
            (in millions)  

Maritza

     Covenant       $ 1,040      $             270  

Sonel

     Covenant         395        382  

Kelanitissa

     Covenant         22        10  
     

 

 

    

Total

      $ 1,457     
     

 

 

    

Included in “Current liabilities of discontinued and held for sale businesses” in the condensed consolidated balance sheet as of June 30, 2011 is approximately $178 million of non-recourse debt relating to our businesses

 

23


Table of Contents

in New York, which has been classified as current due to certain facts and circumstances that create significant uncertainty about the business’s ability to generate sufficient cash flows and remain in compliance with the terms of its contractual obligations in the next twelve months.

None of the subsidiaries that are currently in default are subsidiaries that met the applicable definition of materiality under AES’ corporate debt agreements as of June 30, 2011 in order to trigger an event of default or permit acceleration under such indebtedness. The bankruptcy or acceleration of material amounts of debt at such entities would cause a cross default under the recourse senior secured credit facility. However, as a result of additional dispositions of assets, other significant reductions in asset carrying values or other matters in the future that may impact our financial position and results of operations or the financial position or results of operations of an individual subsidiary, it is possible that one or more of these subsidiaries could fall within the definition of a “material subsidiary” and thereby a bankruptcy or an acceleration of its non-recourse debt trigger an event of default and possible acceleration of the indebtedness under the AES Parent Company’s outstanding debt securities.

Recourse Debt

During the three months ended June 30, 2011, the Company secured recourse debt of $2.05 billion, which may be used as permanent financing for the acquisition of DPL Inc. (“DPL”), as discussed below. On May 27, 2011, the Company secured a $1.05 billion term loan under a senior secured credit facility (the “senior secured term loan”). The senior secured term loan will bear annual interest, at the Company’s option, at a variable rate of LIBOR plus 3.25% or Base Rate plus 2.25%, and will mature on the seventh anniversary of the closing date. The senior secured term loan is subject to certain customary representations, covenants and events of default.

On June 15, 2011, the Company closed on the offering of $1 billion aggregate principal amount of 7.375% senior unsecured notes maturing July 1, 2021 (the “2021 Notes”). Upon a change of control, the Company must offer to repurchase the 2021 Notes at a price equal to 101% of principal, plus accrued interest. The 2021 Notes are also subject to certain covenants restricting the ability of the Company to incur additional secured debt; to enter into sale-lease back transactions; to consolidate, merge, convey or transfer substantially all of its assets; as well as other covenants and events of default that are customary for debt securities like the 2021 Notes.

The proceeds of the senior secured term loan and the 2021 Notes may, among other things, be used to partially finance the Company’s contemplated acquisition of DPL Inc, as discussed further in Note 16 — Acquisitions.

During May 2011, the Company entered into interest rate locks to hedge the risk of changes in LIBOR until the forecasted issuance of the 2021 Notes. The Company paid $24 million to settle those interest rate locks as of June 15, 2011. The payment was recognized in accumulated other comprehensive income and is being amortized over the life of the 2021 Notes.

9. CONTINGENCIES AND COMMITMENTS

Environmental

The Company periodically reviews its obligations as they relate to compliance with environmental laws, including site restoration and remediation. As of June 30, 2011, the Company had recorded liabilities of $26 million for projected environmental remediation costs. Due to the uncertainties associated with environmental assessment and remediation activities, future costs of compliance or remediation could be higher or lower than the amount currently accrued. Based on currently available information and analysis, the Company believes that it is reasonably possible that costs associated with such liabilities, or as yet unknown liabilities, may exceed current reserves in amounts that could be material but cannot be estimated as of June 30, 2011.

 

24


Table of Contents

The Company is subject to numerous environmental laws and regulations in the jurisdictions in which it operates. The Company expenses environmental regulation compliance costs as incurred unless the underlying expenditure qualifies for capitalization under its property, plant and equipment policies. The Company faces certain risks and uncertainties related to these environmental laws and regulations, including existing and potential greenhouse gas (“GHG”) legislation or regulations, and actual or potential laws and regulations pertaining to water discharges, waste management (including disposal of coal combustion byproducts), and certain air emissions, such as SO2, NOx, particulate matter and mercury. Such risks and uncertainties could result in increased capital expenditures or other compliance costs which could have a material adverse effect on certain of our U.S. or international subsidiaries and our consolidated results of operations.

Legislation and Regulation of GHG Emissions

Currently, in the United States there is no federal legislation establishing mandatory GHG emissions reduction programs (including CO2) affecting the electric power generation facilities of the Company’s subsidiaries. There are numerous state programs regulating GHG emissions from electric power generation facilities and there is a possibility that federal GHG legislation will be enacted within the next several years. Further, the United States Environmental Protection Agency (“EPA”) has adopted regulations pertaining to GHG emissions and has announced its intention to propose new regulations for electric generating units under Section 111 of the United States Clean Air Act (“CAA”).

Potential U.S. Federal GHG Legislation    Federal legislation passed the U.S. House of Representatives in 2009 that, if adopted, would have imposed a nationwide cap-and-trade program to reduce GHG emissions. This legislation was never signed into law, and is no longer under consideration. In the U.S. Senate, several different draft bills pertaining to GHG legislation have been considered, including comprehensive GHG legislation similar to the legislation that passed the U.S. House of Representatives and more limited legislation focusing only on the utility and electric generation industry. It is uncertain whether any legislation pertaining to GHG emissions will be voted on and passed by the U.S. Senate and House of Representatives. If any such legislation is enacted into law, the impact could be material to the Company.

EPA GHG Regulation    The EPA has promulgated regulations governing GHG emissions from automobiles under the CAA. The effect of the EPA’s regulation of GHG emissions from mobile sources is that certain provisions of the CAA will also apply to GHG emissions from existing stationary sources, including many U.S. power plants. In particular, beginning January 2, 2011, construction of new stationary sources and modifications to existing stationary sources that result in increased GHG emissions became subject to permitting requirements under the prevention of significant deterioration (“PSD”) program of the CAA. The PSD program, as currently applicable to GHG emissions, requires sources that emit above a certain threshold of GHGs to obtain PSD permits prior to commencement of new construction or modifications to existing facilities. In addition, major sources of GHG emissions may be required to amend, or obtain new, Title V air permits under the CAA to reflect any new applicable GHG emissions requirements for new construction or for modifications to existing facilities.

The EPA promulgated a final rule on June 3, 2010 (the “Tailoring Rule”) that sets thresholds for GHG emissions that would trigger PSD permitting requirements. The Tailoring Rule, which became effective in January of 2011, provides that sources already subject to PSD permitting requirements need to install Best Available Control Technology (“BACT”) for greenhouse gases if a proposed modification would result in the increase of more than 75,000 tons per year of GHG emissions. Also, under the Tailoring Rule, any new sources of GHG emissions that would emit over 100,000 tons per year of GHG emissions, in addition to any modification that would result in GHG emissions exceeding 75,000 tons per year, require PSD review and are subject to related permitting requirements. The EPA anticipates that it will adjust downward the permitting thresholds of 100,000 tons and 75,000 tons for new sources and modifications, respectively, in future rulemaking actions. The Tailoring Rule substantially reduces the number of sources subject to PSD requirements for GHG emissions and the number of sources required to obtain Title V air permits, although new thermal power plants may still be subject to PSD and Title V requirements because annual GHG emissions from such plants typically far exceed

 

25


Table of Contents

the 100,000 ton threshold noted above. The 75,000 ton threshold for increased GHG emissions from modifications to existing sources may reduce the likelihood that future modifications to plants owned by some of our United States subsidiaries would trigger PSD requirements, although some projects that would expand capacity or electric output are likely to exceed this threshold, and in any such cases the capital expenditures necessary to comply with the PSD requirements could be significant.

In December 2010, the EPA entered into a settlement agreement with several states and environmental groups to resolve a petition for review challenging the EPA’s new source performance standards (“NSPS”) rulemaking for electric utility steam generating units (“EUSGUs”) based on the NSPS’s failure to address GHG emissions. Under the settlement agreement, the EPA had committed to propose GHG emissions standards for EUSGUs by July 26, 2011. The EPA has announced that it will delay the proposal of such standards until September 30, 2011. The EPA has also committed to finalize GHG NSPS for EUSGUs by May 26, 2012. The NSPS will establish GHG emission standards for newly constructed and reconstructed EUSGUs. The NSPS also will establish guidelines regarding the best system for achieving further GHG emissions reductions from existing EUSGUs. Based on the guidelines, individual states will be required to develop regulations establishing GHG performance standards for existing EUSGUs within their states. It is impossible to estimate the impact and compliance cost associated with any future NSPS applicable to EUSGUs until such regulations are finalized. However, the compliance costs could have a material and adverse impact on our consolidated financial condition or results of operations.

Regional Greenhouse Gas Initiative    To date, the primary regulation of GHG emissions affecting the Company’s U.S. plants has been through the Regional Greenhouse Gas Initiative (“RGGI”). Under RGGI, ten northeastern states have coordinated to establish rules that require reductions in CO2 emissions from power plant operations within those states through a cap-and-trade program. States participating in RGGI in which our subsidiaries have generating facilities include Connecticut, Maryland, New York and New Jersey. Under RGGI, power plants must acquire one carbon allowance through auction or in the emission trading markets for each ton of CO2 emitted. As noted in the June 2011 Form 8-K, we have estimated the costs to the Company of compliance with RGGI to be approximately $15 million for 2011.

International GHG Regulation    The primary international agreement concerning GHG emissions is the Kyoto Protocol, which became effective on February 16, 2005 and requires the industrialized countries that have ratified it to significantly reduce their GHG emissions. The vast majority of the developing countries which have ratified the Kyoto Protocol have no GHG emissions reduction requirements. Many of the countries in which the Company’s subsidiaries operate have no emissions reduction obligations under the Kyoto Protocol. In addition, of the 28 countries in which the Company’s subsidiaries operate, all but one — the United States (including Puerto Rico) — have ratified the Kyoto Protocol. The first commitment period under the Kyoto Protocol is currently expected to expire at the end of 2012, and countries have been unable to agree on a successor commitment period. The next annual United Nations conference to develop a successor international agreement is scheduled for November 2011 in South Africa. It currently appears unlikely that a successor agreement will be reached at such conference; however, if a successor agreement is reached the impact could be material to the Company.

There is substantial uncertainty with respect to whether U.S. federal GHG legislation will be enacted into law, whether new country-specific GHG legislation will be adopted in countries in which our subsidiaries conduct business, and whether a new international agreement to succeed the Kyoto Protocol will be reached. There is additional uncertainty regarding the final provisions or implementation of any potential U.S. federal or foreign country GHG legislation, the EPA’s rules regulating GHG emissions and any international agreement to succeed the Kyoto Protocol. In light of these uncertainties, the Company cannot accurately predict the impact on its consolidated results of operations or financial condition from potential U.S. federal or foreign country GHG legislation, the EPA’s regulation of GHG emissions or any new international agreement on such emissions, or make a reasonable estimate of the potential costs to the Company associated with any such legislation, regulation or international agreement; however, the impact from any such legislation, regulation or international agreement could have a material adverse effect on certain of our U.S. or international subsidiaries and on the Company and its consolidated results of operations.

 

26


Table of Contents

Other U.S. Air Emissions Regulations and Legislation

The Company’s subsidiaries in the United States are subject to the Clean Air Act (“CAA”) and various state laws and regulations that regulate emissions of air pollutants, including SO2, NOX, particulate matter (“PM”), mercury and other hazardous air pollutants (“HAPs”).

The EPA promulgated the “Clean Air Interstate Rule” (“CAIR”) on March 10, 2005, which required allowance surrender for SO2 and NOX emissions from existing power plants located in 28 eastern states and the District of Columbia. CAIR was subsequently challenged in federal court, and on July 11, 2008, the United States Court of Appeals for the D.C. Circuit issued an opinion striking down much of CAIR and remanding it to the EPA. In response to the D.C. Circuit’s opinion, on July 7, 2011, the EPA issued a final rule titled “Federal Implementation Plans to Reduce Interstate Transport of Fine Particulate Matter and Ozone in 27 States,” which is now referred to as the Cross-State Air Pollution Rule (“CSAPR”). Starting in 2012, the CSAPR requires significant reductions in SO2 and NOx emissions from covered sources, such as power plants, in many states in which subsidiaries of the Company operate. Once fully implemented in 2014, the rule requires additional SO2 emission reductions of 73% and additional NOx reductions of 54% from 2005 levels. The CSAPR will be implemented, in part, through a market-based program under which compliance may be achievable through the acquisition and use of new emissions allowances that the EPA will create. The CSAPR contemplates limited interstate and intra-state trading of emissions allowances by covered sources. Initially, at least through 2012, the EPA will issue emissions allowances to affected power plants based on state emissions budgets established by the EPA under the CSAPR. The availability of and cost to purchase allowances to meet the emission reduction requirements is uncertain at this time. To comply with the CSAPR, additional pollution control technology may be required by some of our subsidiaries, and the cost of implementing any such technology could affect the financial condition or results of operations of these subsidiaries or the Parent Company. Additionally, compliance with the CSAPR could require the purchase of newly issued allowances, the switch to higher priced, lower sulfur coal or the retirement of existing generating units. While the capital costs, other expenditures or operational restrictions necessary to comply with the CSAPR cannot be specified at this time, the Company anticipates that the CSAPR may have a material impact on the Company’s business and results of operations.

As a result of prior EPA determinations and the D.C. Circuit Court ruling, the EPA is obligated under Section 112 of the CAA to develop a rule requiring pollution controls for hazardous air pollutants, including mercury, hydrogen chloride, hydrogen fluoride, and other metal species from coal and oil-fired power plants. The EPA has entered into a consent decree under which it is obligated to finalize the rule by November 2011. In connection with such rule, the CAA requires the EPA to establish maximum achievable control technology (“MACT”) standards for each pollutant regulated under the rule. MACT is defined as the emission limitation achieved by the “best performing 12%” of sources in the source category. The EPA published a proposed rule on May 3, 2011 that would establish national emissions standards for hazardous air pollutants (“NESHAP”) from coal- and oil-fired electric utility steam generating units. The rule, as currently proposed, may require all coal-fired power plants to install acid gas control technology, upgrade particulate control devices and/or install some other type of mercury control technology, such as sorbent injection. The EPA is receiving public comments on the proposed rule and the comment period for the proposed rule has been extended until August 4, 2011. Such public comments will be considered by the EPA prior to promulgating a final rule. Most of the United States coal-fired plants operated by the Company’s subsidiaries have acid gas scrubbers or comparable control technologies, but as proposed there are other improvements to such control technologies that may be needed at some of the Company’s plants. Under the CAA, compliance is required within three years of the effective date of the rule; however, the compliance period for a unit, or group of units, may be extended by state permitting authorities (for one additional year) or through a determination by the President (for up to two additional years). At this time, the Company cannot predict the extent of the final regulations for hazardous air pollutants, but the cost of compliance with any such regulations could be material.

Other International Air Emissions Regulations and Legislation

On January 18, 2011, the President of Chile approved a new air emissions regulation submitted to him by the national environmental regulatory agency (“CONAMA”). The new regulation establishes limits on emissions

 

27


Table of Contents

of NOX, SO2, metals and particulate matter for both existing and new thermal power plants, with more stringent limitations on new facilities. The regulation became effective on June 23, 2011. The regulation will require AES Gener, the Company’s Chilean subsidiary, to install emissions reduction equipment at its existing thermal plants from late 2011 through 2015. The costs of compliance with such regulation have not yet been determined and the Company believes some of the compliance costs are contractually passed through to counterparties. However, the compliance costs could be material.

Cooling Water Intake Regulations

The Company’s U.S. facilities are subject to the U.S. Clean Water Act Section 316(b) rule issued by the EPA which seeks to protect fish and other aquatic organisms by requiring existing steam electric generating facilities to utilize the “best technology available” for cooling water intake structures. The EPA published a proposed rule establishing requirements under 316(b) regulations on April 20, 2011. The proposal, based on Section 316(b) of the U.S. Clean Water Act, establishes Best Technology Available (“BTA”) requirements regarding impingement standards with respect to aquatic organisms for all facilities that withdraw above 2 million gallons per day of water from certain water bodies and utilize at least 25% of the withdrawn water for cooling purposes. To meet these BTA requirements, as currently proposed, cooling water intake structures associated with once through cooling processes will need modifications of existing traveling screens that protect aquatic organisms and will need to add a fish return and handling system for each cooling system. Existing closed cycle cooling facilities may require upgrades to water intake structure systems. The proposal would also require comprehensive site-specific studies during the permitting process and may require closed-cycle cooling systems in order to meet BTA entrainment standards.

The EPA is accepting public comments on the proposed rule until August 18, 2011, and will consider the public comments with a view to issuing a final rule by July of 2012. Until such regulations are final, the EPA has instructed state regulatory agencies to use their best professional judgment in determining how to evaluate what constitutes “best technology available” for protecting fish and other aquatic organisms from cooling water intake structures. Certain states in which the Company operates power generation facilities, such as New York, have been delegated authority and are moving forward with best technology available determinations in the absence of any final rule from the EPA. On September 27, 2010, the California Office of Administrative Law approved a policy adopted by the California Water Resources Control Board with respect to power plant cooling water intake structures. This policy became effective on October 1, 2010, and establishes technology-based standards to implement Section 316(b) of the U.S. Clean Water Act. At this time, it is contemplated that the Company’s Redondo Beach, Huntington Beach and Alamitos power plants in California will need to have in place best technology available by December 31, 2020, or repower the facilities. At present, the Company cannot predict the final requirements under Section 316(b) or whether compliance with the anticipated new 316(b) rule will have a material impact on our operations or results, but the Company expects that capital investments and/or modifications resulting from such requirements could be significant.

Waste Management

In the course of operations, many of the Company’s facilities generate coal combustion byproducts (“CCB”), including fly ash, requiring disposal or processing. On June 21, 2010 the EPA published in the Federal Register a proposed rule to regulate CCB under the Resource Conservation and Recovery Act (“RCRA”). The proposed rule provides two possible options for CCB regulation, and both options contemplate heightened structural integrity requirements for surface impoundments of CCB. The first option contemplates regulation of CCB as a hazardous waste subject to regulation under Subtitle C of the RCRA. Under this option, existing surface impoundments containing CCB would be required to be retrofitted with composite liners and these impoundments would likely be phased out over several years. State and/or federal permit programs would be developed for storage, transport and disposal of CCB. States could bring enforcement actions for non-compliance with permitting requirements, and the EPA would have oversight responsibilities as well as the authority to bring

 

28


Table of Contents

lawsuits for non-compliance. The second option contemplates regulation of CCB under Subtitle D of the RCRA. Under this option, the EPA would create national criteria applicable to CCB landfills and surface impoundments. Existing impoundments would also be required to be retrofitted with composite liners and would likely be phased out over several years. This option would not contain federal or state permitting requirements. The primary enforcement mechanism under regulation pursuant to Subtitle D would be private lawsuits.

The public comment period for this proposed regulation has expired, and the EPA is required to consider the public comments prior to promulgating a final rule. Requirements under a final rule are expected to become effective by January 2012, with a compliance schedule of five years. While the exact impact and compliance cost associated with future regulations of CCB cannot be established until such regulations are finalized, there can be no assurance that the Company’s businesses, financial condition or results of operations would not be materially and adversely affected by such regulations.

Indiana Senate Bill 251

In May 2011, Senate Bill 251 became a law in the State of Indiana. Among other provisions, the law provides Indiana utilities, including IPL, with a means for recovering 80% of costs incurred to comply with federal mandates through a periodic retail rate adjustment mechanism, and additional cost recovery is possible through a subsequent general rate case. This includes, among other things, costs to comply with regulations from the EPA, including capital intensive requirements and/or proposals described herein, such as those relating to cooling water intake regulations, waste management and coal combustion byproducts.

Some of the most important features of Senate Bill 251 to IPL are as follows: any energy utility in Indiana seeking to recover federally mandated costs incurred in connection with a compliance project shall apply to the Indiana Utility Regulatory Commission (“IURC”) for a certificate of public convenience and necessity (“CPCN”) for the compliance project. It sets forth certain factors that the IURC must consider in determining whether to grant a CPCN. It further specifies that if the IURC approves a proposed compliance project and the projected federally mandated costs associated with the project, the following apply: (i) 80% of the approved costs shall be recovered by the energy utility through a periodic retail rate adjustment mechanism; (ii) 20% of the approved costs shall be deferred and recovered by the energy utility as part of the next general rate case filed by the energy utility with the IURC; and (iii) actual costs exceeding the projected federally mandated costs of the approved compliance project by more than 25% shall require specific justification and approval by the IURC before being authorized in the energy utility’s next general rate case.

Guarantees, Letters of Credit and Commitments

In connection with certain project financing, acquisition, power purchase, and other agreements, AES has expressly undertaken limited obligations and commitments, most of which will only be effective or will be terminated upon the occurrence of future events. In the normal course of business, AES has entered into various agreements, mainly guarantees and letters of credit, to provide financial or performance assurance to third parties on behalf of AES businesses. These agreements are entered into primarily to support or enhance the creditworthiness otherwise achieved by a business on a stand-alone basis, thereby facilitating the availability of sufficient credit to accomplish their intended business purposes. Most of the contingent obligations primarily relate to future performance commitments which the Company or its businesses expect to fulfill within the normal course of business. The expiration dates of these guarantees vary from less than one year to more than 15 years.

The following table summarizes the Parent Company’s contingent contractual obligations as of June 30, 2011. Amounts presented in the table below represent the Parent Company’s current undiscounted exposure to guarantees and the range of maximum undiscounted potential exposure. The maximum exposure is not reduced by the amounts, if any, that could be recovered under the recourse or collateralization provisions in the

 

29


Table of Contents

guarantees. The amounts include obligations made by the Parent Company for the direct benefit of the lenders associated with the non-recourse debt of businesses of $27 million.

 

Contingent contractual obligations

   Amount      Number of
Agreements
     Maximum Exposure Range for
Each Agreement
 
     (in millions)             (in millions)  

Guarantees

   $ 362        23        < $1 - $53   

Letters of credit under the senior secured credit facility

     26        11        < $1 - $16   

Cash collateralized letters of credit

     27        11        < $1 - $15   
  

 

 

    

 

 

    

Total

   $         415        45     
  

 

 

    

 

 

    

As of June 30, 2011, the Company had $45 million of commitments to invest in subsidiaries under construction and to purchase related equipment that were not included in the letters of credit discussed above. The Company expects to fund these net investment commitments in 2011. The exact payment schedules will be dictated by the construction milestones. Additionally, subject to regulatory and shareholders’ approvals, the Company is committed to purchase DPL for $3.5 billion, see Note 16 — Acquisitions for further information. We expect to fund these commitments from a combination of current liquidity and internally generated Parent Company cash flow.

Litigation

The Company is involved in certain claims, suits and legal proceedings in the normal course of business, some of which are described below. The Company has accrued for litigation and claims where it is probable that a liability has been incurred and the amount of loss can be reasonably estimated. The Company has evaluated claims in accordance with the accounting guidance for contingencies that it deems both probable and reasonably estimable and accordingly, has recorded aggregate reserves for all claims of approximately $493 million and $448 million as of June 30, 2011 and December 31, 2010, respectively. These reserves are reported on the condensed consolidated balance sheets within “accrued and other liabilities” and “other long-term liabilities.” A significant portion of the reserves relate to employment, non-income tax and customer disputes in international jurisdictions, principally Brazil. Certain of the Company’s subsidiaries, principally in Brazil, are defendants in a number of labor and employment lawsuits. The complaints generally seek unspecified monetary damages, injunctive relief, or other relief. The subsidiaries have denied any liability and intend to vigorously defend themselves in all of these proceedings. There can be no assurance that these reserves will be adequate to cover all existing and future claims or that we will have the liquidity to pay such claims as they arise.

The Company believes, based upon information it currently possesses and taking into account established reserves for liabilities and its insurance coverage, that the ultimate outcome of these proceedings and actions is unlikely to have a material effect on the Company’s financial statements. However, even where no reserve has been recognized, it is reasonably possible that some matters could be decided unfavorably to the Company and could require the Company to pay damages or make expenditures in amounts that could be material but could not be estimated as of June 30, 2011. The material contingencies where a loss is reasonably possible are described below. In aggregate, the Company estimates that the range of potential losses related to these material contingences to be up to $1.9 billion. The amounts considered reasonably possible do not include amounts reserved, as discussed above. Where a loss or range of loss cannot be estimated, a statement to this effect has been included in the applicable case descriptions presented below.

In 1989, Centrais Elétricas Brasileiras S.A. (“Eletrobrás”) filed suit in the Fifth District Court in the State of Rio de Janeiro against Eletropaulo Eletricidade de São Paulo S.A. (“EEDSP”) relating to the methodology for calculating monetary adjustments under the parties’ financing agreement. In April 1999, the Fifth District Court found for Eletrobrás and in September 2001, Eletrobrás initiated an execution suit in the Fifth District Court to collect approximately R$1.2 billion ($765 million) from Eletropaulo (as estimated by Eletropaulo) and a lesser

 

30


Table of Contents

amount from an unrelated company, Companhia de Transmissão de Energia Elétrica Paulista (“CTEEP”) (Eletropaulo and CTEEP were spun off from EEDSP pursuant to its privatization in 1998). In November 2002, the Fifth District Court rejected Eletropaulo’s defenses in the execution suit. Eletropaulo appealed and in September 2003, the Appellate Court of the State of Rio de Janeiro (“AC”) ruled that Eletropaulo was not a proper party to the litigation because any alleged liability had been transferred to CTEEP pursuant to the privatization. In June 2006, the Superior Court of Justice (“SCJ”) reversed the Appellate Court’s decision and remanded the case to the Fifth District Court for further proceedings, holding that Eletropaulo’s liability, if any, should be determined by the Fifth District Court. Eletropaulo’s subsequent appeals to the Special Court (the highest court within the SCJ) and the Supreme Court of Brazil were dismissed. Eletrobrás later requested that the amount of Eletropaulo’s alleged debt be determined by an accounting expert appointed by the Fifth District Court. Eletropaulo consented to the appointment of such an expert, subject to a reservation of rights. In February 2010, the Fifth District Court appointed an accounting expert to determine the amount of the alleged debt and the responsibility for its payment in light of the privatization, in accordance with the methodology proposed by Eletrobrás. Pursuant to its reservation of rights, Eletropaulo filed an interlocutory appeal with the AC asserting that the expert was required to determine the issues in accordance with the methodology proposed by Eletropaulo, and that Eletropaulo should be entitled to take discovery and present arguments on the issues to be determined by the expert. In April 2010, the AC issued a decision agreeing with Eletropaulo’s arguments and directing the Fifth District Court to proceed accordingly. Eletrobrás has restarted the accounting proceedings at the Fifth District Court, which will proceed in accordance with the AC’s April 2010 decision. In the Fifth District Court proceedings, the expert’s conclusions will be subject to the Fifth District Court’s review and approval. If Eletropaulo is determined to be responsible for the debt, after the amount of the alleged debt is determined, Eletrobrás will be entitled to resume the execution suit in the Fifth District Court at any time. If Eletrobrás does so, Eletropaulo will be required to provide security in the amount of its alleged liability. In that case, if Eletrobrás requests the seizure of such security and the Fifth District Court grants such request, Eletropaulo’s results of operations may be materially adversely affected, and in turn the Company’s results of operations could be materially adversely affected. In addition, in February 2008, CTEEP filed a lawsuit in the Fifth District Court against Eletrobrás and Eletropaulo seeking a declaration that CTEEP is not liable for any debt under the financing agreement. The parties are disputing the proper venue for the CTEEP lawsuit. Eletropaulo believes it has meritorious defenses to the claims asserted against it and will defend itself vigorously in these proceedings; however, there can be no assurances that it will be successful in its efforts.

In August 2001, the Grid Corporation of Orissa, India, now Gridco Ltd. (“Gridco”), filed a petition against the Central Electricity Supply Company of Orissa Ltd. (“CESCO”), an affiliate of the Company, with the Orissa Electricity Regulatory Commission (“OERC”), alleging that CESCO had defaulted on its obligations as an OERC-licensed distribution company, that CESCO management abandoned the management of CESCO, and seeking for interim measures of protection, including the appointment of an administrator to manage CESCO. Gridco, a state-owned entity, is the sole wholesale energy provider to CESCO. Pursuant to the OERC’s August 2001 order, the management of CESCO was replaced with a government administrator who was appointed by the OERC. The OERC later held that the Company and other CESCO shareholders were not necessary or proper parties to the OERC proceeding. In August 2004, the OERC issued a notice to CESCO, the Company and others giving the recipients of the notice until November 2004 to show cause why CESCO’s distribution license should not be revoked. In response, CESCO submitted a business plan to the OERC. In February 2005, the OERC issued an order rejecting the proposed business plan. The order also stated that the CESCO distribution license would be revoked if an acceptable business plan for CESCO was not submitted to and approved by the OERC prior to March 31, 2005. In its April 2, 2005 order, the OERC revoked the CESCO distribution license. CESCO has filed an appeal against the April 2, 2005 OERC order and that appeal remains pending in the Indian courts. In addition, Gridco asserted that a comfort letter issued by the Company in connection with the Company’s indirect investment in CESCO obligates the Company to provide additional financial support to cover all of CESCO’s financial obligations to Gridco. In December 2001, Gridco served a notice to arbitrate pursuant to the Indian Arbitration and Conciliation Act of 1996 on the Company, AES Orissa Distribution Private Limited (“AES ODPL”), and Jyoti Structures (“Jyoti”) pursuant to the terms of the CESCO Shareholders Agreement between Gridco, the Company, AES ODPL, Jyoti and CESCO (the “CESCO arbitration”). In the arbitration, Gridco appeared to be seeking approximately $189 million in

 

31


Table of Contents

damages, plus undisclosed penalties and interest, but a detailed alleged damage analysis was not filed by Gridco. The Company counterclaimed against Gridco for damages. In June 2007, a 2-to-1 majority of the arbitral tribunal rendered its award rejecting Gridco’s claims and holding that none of the respondents, the Company, AES ODPL, or Jyoti, had any liability to Gridco. The respondents’ counterclaims were also rejected. In September 2007, Gridco filed a challenge of the arbitration award with the local Indian court. In June 2008, Gridco filed a separate application with the local Indian court for an order enjoining the Company from selling or otherwise transferring its shares in Orissa Power Generation Corporation Ltd. (“OPGC”), an equity method investment of the Company, and requiring the Company to provide security in the amount of the contested damages in the CESCO arbitration until Gridco’s challenge to the arbitration award is resolved. In June 2010, a 2-to-1 majority of the arbitral tribunal awarded the Company some of its costs relating to the arbitration. In August 2010, Gridco filed a challenge of the cost award with the local Indian court. The Company believes that it has meritorious defenses to the claims asserted against it and will defend itself vigorously in these proceedings; however, there can be no assurances that it will be successful in its efforts.

In March 2003, the office of the Federal Public Prosecutor for the State of São Paulo, Brazil (“MPF”) notified AES Eletropaulo that it had commenced an inquiry related to the BNDES financings provided to AES Elpa and AES Transgás and the rationing loan provided to Eletropaulo, changes in the control of Eletropaulo, sales of assets by Eletropaulo and the quality of service provided by Eletropaulo to its customers, and requested various documents from Eletropaulo relating to these matters. In July 2004, the MPF filed a public civil lawsuit in the Federal Court of São Paulo (“FSCP”) alleging that BNDES violated Law 8429/92 (the Administrative Misconduct Act) and BNDES’s internal rules by: (1) approving the AES Elpa and AES Transgás loans; (2) extending the payment terms on the AES Elpa and AES Transgás loans; (3) authorizing the sale of Eletropaulo’s preferred shares at a stock-market auction; (4) accepting Eletropaulo’s preferred shares to secure the loan provided to Eletropaulo; and (5) allowing the restructurings of Light Serviços de Eletricidade S.A. and Eletropaulo. The MPF also named AES Elpa and AES Transgás as defendants in the lawsuit because they allegedly benefited from BNDES’s alleged violations. In May 2006, the FCSP ruled that the MPF could pursue its claims based on the first, second, and fourth alleged violations noted above. The MPF subsequently filed an interlocutory appeal with the Federal Court of Appeals (“FCA”) seeking to require the FCSP to consider all five alleged violations. Also, in July 2006, AES Elpa and AES Transgás filed an interlocutory appeal with the FCA, which was subsequently consolidated with the MPF’s interlocutory appeal, seeking a transfer of venue and to enjoin the FCSP from considering any of the alleged violations. In June 2009, the FCA granted the injunction sought by AES Elpa and AES Transgás and transferred the case to the Federal Court of Rio de Janeiro. In May 2010, the MPF filed an appeal with the Superior Court of Justice challenging the transfer. The MPF’s lawsuit before the FCSP has been stayed pending a final decision on the interlocutory appeals. AES Elpa and AES Brasiliana (the successor of AES Transgás) believe they have meritorious defenses to the allegations asserted against them and will defend themselves vigorously in these proceedings; however, there can be no assurances that they will be successful in their efforts.

In July 2004, the Corporación Dominicana de Empresas Eléctricas Estatales (“CDEEE”) filed lawsuits against Itabo, an affiliate of the Company, in the First and Fifth Chambers of the Civil and Commercial Court of First Instance for the National District. CDEEE alleges in both lawsuits that Itabo spent more than was necessary to rehabilitate two generation units of an Itabo power plant and, in the Fifth Chamber lawsuit, that those funds were paid to affiliates and subsidiaries of AES Gener and Coastal Itabo, Ltd. (“Coastal”), a former shareholder of Itabo, without the required approval of Itabo’s board of administration. In the First Chamber lawsuit, CDEEE seeks an accounting of Itabo’s transactions relating to the rehabilitation. In November 2004, the First Chamber dismissed the case for lack of legal basis. On appeal, in October 2005 the Court of Appeals of Santo Domingo ruled in Itabo’s favor, reasoning that it lacked jurisdiction over the dispute because the parties’ contracts mandated arbitration. The Supreme Court of Justice is considering CDEEE’s appeal of the Court of Appeals’ decision. In the Fifth Chamber lawsuit, which also names Itabo’s former president as a defendant, CDEEE seeks $15 million in damages and the seizure of Itabo’s assets. In October 2005, the Fifth Chamber held that it lacked jurisdiction to adjudicate the dispute given the arbitration provisions in the parties’ contracts. The First Chamber of the Court of Appeal ratified that decision in September 2006. In a related proceeding, in May 2005, Itabo filed a lawsuit in the U.S. District Court for the Southern District of New York seeking to compel CDEEE to arbitrate

 

32


Table of Contents

its claims. The petition was denied in July 2005. Itabo’s appeal of that decision to the U.S. Court of Appeals for the Second Circuit has been stayed since September 2006. Further, in September 2006, in an International Chamber of Commerce arbitration, an arbitral tribunal determined that it lacked jurisdiction to decide arbitration claims concerning these disputes. Itabo believes it has meritorious claims and defenses and will assert them vigorously in these proceedings; however, there can be no assurances that it will be successful in its efforts.

In July 2007, the Competition Committee of the Ministry of Industry and Trade of the Republic of Kazakhstan (the “Competition Committee”) ordered Nurenergoservice, an AES subsidiary, to pay approximately KZT 18 billion ($123 million) for alleged antimonopoly violations in 2005 through the first quarter of 2007. The Competition Committee’s order was affirmed by the economic court in April 2008 (“April 2008 Decision”). The economic court also issued an injunction to secure Nurenergoservice’s alleged liability, freezing Nurenergoservice’s bank accounts and prohibiting Nurenergoservice from transferring or disposing of its property. Nurenergoservice’s subsequent appeals to the court of appeals were rejected. In February 2009, the Antimonopoly Agency (the Competition Committee’s successor) seized approximately KZT 778 million ($5 million) from a frozen Nurenergoservice bank account in partial satisfaction of Nurenergoservice’s alleged damages liability. However, on appeal to the Kazakhstan Supreme Court, in October 2009, the Supreme Court annulled the decisions of the lower courts because of procedural irregularities and remanded the case to the economic court for reconsideration. On remand, in January 2010, the economic court reaffirmed its April 2008 Decision. Nurenergoservice’s appeals in the court of appeals (first panel) and the court of appeals (second panel) were unsuccessful. Nurenergoservice intends to file a further appeal to the Kazakhstan Supreme Court. In separate but related proceedings, in August 2007, the Competition Committee ordered Nurenergoservice to pay approximately KZT 1.8 billion ($12 million) in administrative fines for its alleged antimonopoly violations. Nurenergoservice’s appeal to the administrative court was rejected in February 2009. Given the adverse court decisions against Nurenergoservice, the Antimonopoly Agency may attempt to seize Nurenergoservice’s remaining assets, which are immaterial to the Company’s consolidated financial statements. The Antimonopoly Agency has not indicated whether it intends to assert claims against Nurenergoservice for alleged antimonopoly violations post first quarter 2007. Nurenergoservice believes it has meritorious defenses to the claims asserted against it; however, there can be no assurances that it will prevail in these proceedings.

In April 2009, the Antimonopoly Agency initiated an investigation of the power sales of Ust-Kamenogorsk HPP (“UK HPP”) and Shulbinsk HPP, hydroelectric plants under AES concession (collectively, the “Hydros”), in January through February 2009. The investigation of both Hydros has now been completed. The Antimonopoly Agency determined that the Hydros abused their market position and charged monopolistically high prices for power in January through February 2009. The Agency sought an order from the administrative court requiring UK HPP to pay an administrative fine of approximately KZT 120 million ($1 million) and to disgorge profits for the period at issue, estimated by the Antimonopoly Agency to be approximately KZT 440 million ($3 million). No fines or damages have been paid to date, however, as the proceedings in the administrative court have been suspended due to the initiation of related criminal proceedings against officials of the Hydros. In the course of criminal proceedings, the financial police have expanded the periods at issue to the entirety of 2009 in the case of UK HPP and from January through October 2009 in the case of Shulbinsk HPP, and sought increased damages of KZT 1.2 billion ($8 million) in the case of UK HPP and KZT 1.3 billion ($9 million) in the case of Shulbinsk HPP. The Hydros believe they have meritorious defenses and will assert them vigorously in these proceedings; however, there can be no assurances that they will be successful in their efforts.

In July 1993, the Public Attorney’s office filed a claim against Eletropaulo, the Sao Paulo State Government, SABESP (a state-owned company), CETESB (the Environmental Agency of Sao Paulo State) and DAEE (the municipal Water and Electric Energy Department) alleging that they were liable for pollution of the Billings Reservoir as a result of pumping water from the Pinheiros River into the Billings Reservoir. The events in question occurred while Eletropaulo was a state-owned company. An initial lower court decision in 2007 found the parties liable for the payment of approximately R$733 million ($467 million) for remediation. Eletropaulo subsequently appealed the decision to the Appellate Court of the State of Sao Paulo which reversed the lower court decision. In 2009, the Public Attorney’s Office filed appeals to both the Superior Court of Justice

 

33


Table of Contents

and the Supreme Court and such appeals were answered by Eletropaulo in the fourth quarter of 2009. Eletropaulo believes it has meritorious defenses to the claims asserted against it and will defend itself vigorously in these proceedings; however, there can be no assurances that it will be successful in its efforts.

In February 2009, a CAA Section 114 information request from the EPA regarding Cayuga and Somerset was received. The request seeks various operating and testing data and other information regarding certain types of projects at the Cayuga and Somerset facilities, generally for the time period from January 1, 2000 through the date of the information request. This type of information request has been used in the past to assist the EPA in determining whether a plant is in compliance with applicable standards under the CAA. Cayuga and Somerset responded to the EPA’s information request in June 2009, and they are awaiting a response from the EPA regarding their submittal. At this time, it is not possible to predict what impact, if any, this request may have on the Company, its results of operations or its financial position.

On February 2, 2009, the Cayuga facility received a Notice of Violation from the New York State Department of Environmental Conservation (“NYSDEC”) that the facility had exceeded the permitted volume limit of coal ash that can be disposed of in the on-site landfill. Cayuga has met with NYSDEC and submitted a Landfill Liner Demonstration Report to them. Such report found that the landfill has adequate engineering integrity to support the additional coal ash and there is no inherent environmental threat. NYSDEC has indicated they accept the finding of the report. A permit modification was approved by the NYSDEC on May 14, 2010 and such permit modification allows for closure of this approximately 10-acre portion of the landfill. The construction in accordance with the approved permit modification was completed in November 2010 and the certification report for this construction project was submitted to the NYSDEC in the second quarter of 2011. While at this time it is not possible to predict what impact, if any, this matter may have on the Company, its results of operations or its financial position, based upon the discussions to date, the Company does not believe the impact will be material.

In March 2009, AES Uruguaiana Empreendimentos S.A. (“AESU”) initiated arbitration in the International Chamber of Commerce (“ICC”) against YPF S.A. (“YPF”) seeking damages and other relief relating to YPF’s breach of the parties’ gas supply agreement (“GSA”). Thereafter, in April 2009, YPF initiated arbitration in the ICC against AESU and two unrelated parties, Companhia de Gas do Esado do Rio Grande do Sul and Transportador de Gas del Mercosur S.A. (“TGM”), claiming that AESU wrongfully terminated the GSA and caused the termination of a transportation agreement (“TA”) between YPF and TGM (“YPF Arbitration”). YPF seeks an unspecified amount of damages from AESU, a declaration that YPF’s performance was excused under the GSA due to certain alleged force majeure events, or, in the alternative, a declaration that the GSA and the TA should be terminated without a finding of liability against YPF because of the allegedly onerous obligations imposed on YPF by those agreements. In addition, in the YPF Arbitration, TGM asserts that if it is determined that AESU is responsible for the termination of the GSA, AESU is liable for TGM’s alleged losses, including losses under the TA. In April 2011, the arbitrations were consolidated into a single proceeding, and a new procedural schedule was established for the consolidated proceeding. The hearing on liability issues will take place in December 2011. AESU believes it has meritorious claims and defenses and will assert them vigorously; however, there can be no assurances that it will be successful in its efforts.

In June 2009, the Inter-American Commission on Human Rights of the Organization of American States (“IACHR”) requested that the Republic of Panama suspend the construction of AES Changuinola S.A.’s hydroelectric project (“Project”) until the bodies of the Inter-American human rights system can issue a final decision on a petition (286/08) claiming that the construction violates the human rights of alleged indigenous communities. In July 2009, Panama responded by informing the IACHR that it would not suspend construction of the Project and requesting that the IACHR revoke its request. In June 2010, the Inter-American Court of Human Rights vacated the IACHR’s request. With respect to the merits of the underlying petition, the IACHR heard arguments by the communities and Panama in November 2009, but has not issued a decision to date. The Company cannot predict Panama’s response to any determination on the merits of the petition by the bodies of the Inter-American human rights system.

 

34


Table of Contents

In July 2009, AES Energía Cartagena S.R.L. (“AES Cartagena”) received notices from the Spanish national energy regulator, Comisión Nacional de Energía (“CNE”), stating that the proceeds of the sale of electricity from AES Cartagena’s plant should be reduced by roughly the value of the CO2 allowances that were granted to AES Cartagena for free for the years 2007, 2008, and the first half of 2009. In particular, the notices stated that CNE intended to invoice AES Cartagena to recover that value, which CNE calculated as approximately €20 million ($29 million) for 2007-2008 and an amount to be determined for the first half of 2009. In September 2009, AES Cartagena received invoices for €523,548 (approximately $753,000) for the allowances granted for free for 2007 and €19,907,248 (approximately $29 million) for 2008. In July 2010, AES Cartagena received an invoice for approximately €5 million ($7 million) for the allowances granted for free for the first half of 2009. AES Cartagena does not expect to be charged for CO2 allowances issued free of charge for subsequent periods. AES Cartagena has paid the amounts invoiced and has filed challenges to the CNE’s demands in the Spanish judicial system. There can be no assurances that the challenges will be successful. AES Cartagena has demanded indemnification from its fuel supply and electricity toller, GDF-Suez, in relation to the CNE invoices under the long-term energy agreement (the “Energy Agreement”) with GDF-Suez. However, GDF-Suez has disputed that it is responsible for the CNE invoices under the Energy Agreement. Therefore, in September 2009, AES Cartagena initiated arbitration against GDF-Suez, seeking to recover the payments made to CNE. In the arbitration, AES Cartagena also seeks a determination that GDF-Suez is responsible for procuring and bearing the cost of CO2 allowances that are required to offset the CO2 emissions of AES Cartagena’s power plant, which is also in dispute between the parties. To date, AES Cartagena has paid approximately €25 million ($36 million) for the CO2 allowances that have been required to offset 2008, 2009 and 2010 CO2 emissions. AES Cartagena expects that allowances will need to be purchased to offset emissions for subsequent years. The evidentiary hearing in the arbitration took place from May 31-June 4, 2010, and closing arguments were heard on September 1, 2010. In February 2011, the arbitral tribunal requested further briefing on certain issues in the arbitration, which was later submitted by the parties. The tribunal has the matter under consideration. If AES Cartagena does not prevail in the arbitration and is required to bear the cost of carbon compliance, its results of operations could be materially adversely affected and, in turn, there could be a material adverse effect on the Company and its results of operations. AES Cartagena believes it has meritorious claims and will assert them vigorously in these proceedings; however, there can be no assurances that it will be successful in its efforts.

In November 2009, April 2010, December 2010, April 2011, and June 2011, substantially similar personal injury lawsuits were filed by a total of 45 residents and decedent estates in the Dominican Republic against the Company, AES Atlantis, Inc., AES Puerto Rico, LP, AES Puerto Rico, Inc., and AES Puerto Rico Services, Inc., in the Superior Court for the State of Delaware. In each lawsuit the plaintiffs allege that the coal combustion byproducts of AES Puerto Rico’s power plant were illegally placed in the Dominican Republic from October 2003 through March 2004 and subsequently caused the plaintiffs’ birth defects, other personal injuries, and/or deaths. The plaintiffs do not quantify their alleged damages, but generally allege that they are entitled to compensatory and punitive damages. The AES defendants moved for partial dismissal of both the November 2009 and April 2010 lawsuits on various grounds. In July 2011, the Superior Court dismissed the plaintiffs’ international law and punitive damages claims, but held that the plaintiffs had stated intentional tort, negligence, and strict liability claims under Dominican law, which the Superior Court found governed the lawsuits. The Superior Court granted the plaintiffs leave to amend their complaints in accordance with its decision. The AES defendants will respond to the December 2010, April 2011, and June 2011 lawsuits after the plaintiffs file amended complaints. The AES defendants believe they have meritorious defenses to the claims asserted against them and will defend themselves vigorously; however, there can be no assurances that they will be successful in their efforts.

On December 21, 2010, AES-3C Maritza East 1 EOOD, which owns an unfinished 670 MW lignite-fired power plant in Bulgaria, made the first in a series of demands on the performance bond securing the construction Contractor’s obligations under the parties’ EPC Contract. The Contractor failed to complete the plant on schedule. The total amount demanded by Maritza under the performance bond was approximately €155 million ($223 million). The Contractor obtained an injunction from a lower French court purportedly preventing the issuing bank from honoring the bond demands. However, the Versailles Court of Appeal canceled the injunction

 

35


Table of Contents

in July 2011, and therefore the issuing bank paid the bond demands in full. The Contractor failed to obtain relief from the arbitral tribunal requiring that the funds be reimbursed to the Contractor pending the determination of the arbitration described below. The Contractor may attempt to seek relief in the bond dispute in the French or English courts. In addition, in December 2010, the Contractor stopped commissioning of the power plant’s two units because of the alleged characteristics of the lignite supplied to it for commissioning. In January 2011, the Contractor initiated arbitration on its lignite claim, seeking an extension of time to complete the power plant, an increase to the contract price of approximately €62 million ($89 million), and other relief, including in relation to the bond demands. The Contractor later added claims seeking further extensions of time and an additional €10 million ($14 million) relating to the alleged unavailability of the grid during commissioning. Maritza rejected the Contractor’s claims and asserted counterclaims for delay liquidated damages and other relief relating to the Contractor’s failure to complete the power plant and other breaches of the EPC Contract. Maritza also terminated the EPC Contract for cause and asserted arbitration claims against the Contractor relating to the termination. The Contractor has asserted counterclaims relating to the termination. The arbitral hearing on the merits is in September 2012. Maritza believes it has meritorious claims and defenses and will assert them vigorously in these proceedings; however, there can be no assurances that it will be successful in its efforts.

10. PENSION PLANS

Total pension cost for the three and six months ended June 30, 2011 and 2010 included the following components:

 

     Three Months Ended June 30,     Six Months Ended June 30,  
     2011     2010     2011     2010  
     U.S.     Foreign     U.S.     Foreign     U.S.     Foreign     U.S.     Foreign  
     (in millions)     (in millions)  

Service cost

   $ 2     $ 5     $ 1     $ 4     $ 4     $ 10     $ 3     $ 9  

Interest cost

     8       149       8       126       16       291       16       251  

Expected return on plan assets

     (8     (133     (7     (105     (16     (261     (15     (210

Amortization of prior service cost

     1       -        1       -        2       -        2       -   

Amortization of net loss

     4       6       3       4       7       12       6       7  

Loss on curtailment

     -        -        -        -    &